Q3 2025 Orsted AS Earnings Call

November 5, 2025

Speaker #1: Welcome to this Orsted Q3 2025 Earnings Call . For the first part of this call . All participants will be in listen only mode and afterwards there will be a question and answer session .

Operator: Welcome to this Ørsted's Q3 2025 Earnings Call. For the first part of this call, all participants will be in listen-only mode, and afterwards there will be a question and answer session. Today's speakers are Group President and CEO, Rasmus Errboe and CFO, Trond Westlie. Speakers, please begin.

Speaker #1: Today's speakers are group president and CEO Rasmus Errboe and CFO Trond Westlie . Speakers , please begin .

Speaker #2: Hello everyone .

Rasmus Errboe: Hello, everyone. During the Q3 of the year, we have continued our focus on the execution of the four strategic priorities that we presented in February. These will continue to be the core focus as we execute on our strategy. Let me start by going through our progress across the four priorities. Our first priority is to strengthen our capital structure, and with the completion of the rights issue in early October, we have taken a significant step on this priority. The rights issue strengthens our financial foundation, allows us to focus on delivering our six offshore wind farms under construction, provides the financial robustness to manage the ongoing challenges and uncertainty, as well as the financial strength to pursue upcoming attractive opportunities within offshore wind.

Speaker #3: During the third quarter of the year , we have continued our focus on the execution of the four strategic priorities that we presented in February .

Speaker #3: These will continue to be the core focus as we execute on our strategy . Let me start by going through our progress across the four priorities .

Speaker #3: Okay . Our .

Speaker #4: Our first priority .

Speaker #2: Is to strengthen our capital structure . And with the completion of the rights issue in early October , we have taken a significant step on this property .

Speaker #2: The rights issue strengthens our financial foundation , allows us to focus on delivering our six offshore wind farms under construction , provides the financial robustness to manage the ongoing challenges and uncertainty , as well as the financial strength to pursue upcoming attractive opportunities within offshore wind .

Speaker #2: I am very pleased and grateful for the strong support that we received from our shareholders in the rights issue , including from our majority shareholder , the Danish State .

Rasmus Errboe: I am very pleased and grateful for the strong support that we received from our shareholders in the rights issue, including from our majority shareholder, the Danish state. We announced on 3 November that we have entered into an agreement with Apollo to divest a 50% ownership share in both the project and associated transmission asset for our 2.9GW Hornsea Three project in the UK. The total value of the transaction is approximately DKK 39 billion, the transaction supports a further strengthening of our capital structure and marks a significant milestone in our partnership and divestment program. Another important element in supporting our capital structure is the continued performance of our operational portfolio.

Speaker #2: Also , we announced on November 3rd that we have entered into an agreement with Apollo to divest a 50% ownership share in both the project and associated transmission assets for our 2.9GW Hornsea Three project in the UK .

Speaker #2: The total value of the transaction is approximately 39 billion , and the transaction supports a further strengthening of our capital structure and marks a significant milestone in our partnership and divestment programme .

Speaker #2: Another important element in supporting our capital structure is the continued performance of our operational portfolio . Even though wind been below the norm thus far in the year .

Rasmus Errboe: Even though wind speeds have been below the norm thus far in the year, we have delivered DKK 17 billion of EBITDA for the first nine months of the year, which is mainly driven by the increase in the availability across our offshore portfolio due to strong performance every single day by our generation team. We remain on track to deliver earnings in the range of DKK 24 to 27 billion for the full year. Our second priority is to deliver on our 8.1 GW offshore wind construction portfolio, and we continue to make good progress across the projects, which upon completion will contribute with an annual EBITDA run rate of DKK 11 to 12 billion.

Speaker #2: We have delivered $17 billion of EBITDA for the first nine months of the year , which is mainly driven by the increase in the availability across our offshore portfolio due to strong performance every single day by our generation team .

Speaker #2: We remain on track to deliver earnings in the range of 24 to 27 billion for the full year . Our second priority is to deliver on our 8.1GW offshore speeds have construction portfolio , and we continue to make good progress across the projects , which , upon completion , will contribute with an annual EBITDA run rate of 11 to 12 billion .

Speaker #2: I will shortly go through the construction progress details , but first I want to mention the stop work order , which Revolution Wind received in the US during the third quarter , instructing the project to halt offshore activities pending completion of the Interior Department's review required by the executive order issued on January 20th .

Rasmus Errboe: I will shortly go through the construction progress details. First, I want to mention the stop work order which Revolution Wind received in the US during Q3, instructing the project to halt offshore activities pending completion of the interior department's review required by the executive order issued on 20 January. Revolution Wind continues to seek a complete resolution, both by engaging with the US administration and other stakeholders, as well as through legal proceedings. As part of the legal part, the project filed a lawsuit and sought a preliminary injunction, which was granted on 22 February by the court while the lawsuit is ongoing.

Speaker #2: Revolution Wind continues to seek a complete resolution , both by engaging with the US administration and other stakeholders , as well as through legal proceedings .

Speaker #2: As part of the legal part , the project filed a lawsuit and sought a preliminary injunction , which was granted on February 22nd by the court .

Speaker #2: While the lawsuit is ongoing , the offshore activities have resumed and since then progressed well . Our third priority is to ensure a focused and disciplined capital allocation , always prioritizing value over volume , where our focus going forward primarily will be on offshore wind in Europe and select markets in APAC .

Rasmus Errboe: The offshore activities have resumed and since then progressed well. Our third priority is to ensure a focused and disciplined capital allocation, always prioritizing value over volume, where our focus going forward primarily will be on offshore wind in Europe and select markets in APAC. As part of these efforts, we will move towards a more flexible partnership and financing model in order to improve value creation and ensure risk diversification. On this basis, we recently entered into memorandum of understandings with KOEN and POSCO for our 1.4 gigawatt Incheon offshore wind project in Korea. The aim is to explore cooperation on joint development, construction and operations, including potential equity participation. Finally, on our fourth priority, we have also taken steps in improving our competitiveness with the announcements of adjustments to our organization.

Speaker #2: As part of these efforts , we will move towards a more flexible partnership and financing model in order to improve value creation and ensure risk diversification .

Speaker #2: On this basis , we recently entered into Memorandum of Understanding with Cohen and Posco for our 1.4GW offshore wind project in Korea . The aim is to explore cooperation on joint development , construction and operations , including potential equity participation .

Speaker #2: Finally , on our fourth priority , we have also taken steps in improving our competitiveness with the announcements of adjustments to our organization due to the sharpened strategic focus of our business going forward , and the fact that we will be finalising our large construction portfolio in the coming years .

Rasmus Errboe: Due to the sharpened strategic focus of our business going forward, and the fact that we will be finalizing our large construction portfolio in the coming years, we will adjust our organization accordingly to become more efficient and flexible. Once all efficiency measures have been implemented, the annual cost savings are expected to amount to approximately DKK 2 billion from 2028. The cost savings related to these efficiency measures have been incorporated into our business plan. Let's turn to slide 5, where I will talk through some of the operational highlights for the first nine months. First, I am pleased with the operational performance with our EBITDA, excluding new partnerships and cancellation fees amounting to DKK 17 billion for the first nine months.

Speaker #2: We will adjust our organization accordingly to become more efficient and flexible once all efficiency measures have been implemented . The annual cost savings are expected to amount to approximately 2 billion from 2028 .

Speaker #2: The cost savings related to these efficiency measures have been incorporated into our business plan . Let's turn to slide five , where I will talk through some of the operational highlights for the first nine months .

Speaker #2: First , I am pleased with the operational performance with our EBITDA . Excluding new partnerships and cancellation fees amounting to 17 billion for the first nine months .

Speaker #2: Despite the fact that wind speeds have been below the norm so far this year . Our strong generation performance ensures we remain on track towards delivering our full year guidance of 24 to 27 billion of EBITDA .

Rasmus Errboe: Despite the fact that wind speeds have been below the norm so far this year, our strong generation performance ensures we remain on track towards delivering our full year guidance of DKK 24 to 27 billion of EBITDA. This is mainly driven by high availability within our offshore business, which stood at 93 for the first nine months. Compared to same period last year, this is an increase of 7 percentage points and thus ensured a material earnings contribution. Market-leading performance of our 10 GW offshore wind fleet is a key priority for us, and we are progressing several measures within our generation organization to improve our output and lower cost base through portfolio and operational efficiencies, technological innovation, standardization, and generation excellence. During the quarter, we also made progress on the renewable share of our generation.

Speaker #2: This is mainly driven by higher variability within our offshore business , which stood at 93 for the first nine months compared to same period last year .

Speaker #2: This is an increase of seven percentage points and thus ensured a material earnings contribution . Market leading performance of our offshore wind fleet is a key priority for us , and we are progressing several measures within our generation organization to improve our output and lower cost base through portfolio and operational efficiencies .

Speaker #2: Technological innovation , standardization and generation excellence . During the quarter , we also made progress on the renewable share of our generation . For several years , we have had a target that renewables should consist of 99% of our generation .

Rasmus Errboe: For several years, we have had a target that renewables should consist of 99% of our generation by 2025. This has been the case during the first 9 months of the year. The increased share of renewables was driven by the closing of our last coal fuel-fueled CHP plant in the second half of 2024, which marked another important milestone on our decarbonization journey. Lastly, our continued and relentless focus on safety have continued. The total recordable injury rate for the first 9 months of 2025 is at 2.5, which is in line with our target. This remains highest priority for us. We are continuing an internal program across the full organization, which is intended to further increase training, safety awareness, and management focus, all aimed at lowering the incident rate and bringing our people home safe every day.

Speaker #2: By 2025 , and this has been the case during the first nine months of the year . The increased share of renewables was driven by the closing of our last coal fuelled CHP plant in the second half of 2024 , which marked another important milestone on our journey .

Speaker #2: Lastly , our continued and relentless focus on safety have continued and the total recordable injury rate for the first nine months of 2025 is at 2.5 , which is in line with our target .

Speaker #2: This remains highest priority for us and we are continuing an internal program across the full organization , which is intended to further increase training , safety awareness and management focus .

Speaker #2: All aimed at lowering the incident rate and bringing our people home safe every day . Let's turn to slide six and an overview of our construction projects .

Rasmus Errboe: Let's turn to slide 6 and an overview of our construction projects. I will cover the more advanced projects individually and in more details as usual on the next slides, while putting a few remarks on the remainder of the construction portfolio here. For Borkum Riffgrund 3 in Germany, we have installed all foundations and turbines. Commissioning of the grid connection for Borkum 3 has started according to plan. We expect first power before the end of the year, and the project is expected to be commissioned towards the end of Q1 2026. For Hornsea 3 in the UK, construction is progressing well. The onshore works at the landfall cable route and converter stations have progressed in line with the schedule since last quarter. For the offshore scope, the project will be using two HVDC offshore converter stations.

Speaker #2: I will cover the more advanced projects individually and in more detail as usual . On the next slides . While putting a few remarks on the remainder of the construction portfolio .

Speaker #2: Here . For Borkum , Ripken , three , in Germany , we have installed all foundations and turbines . Commissioning of the grid connection for Borkum three has started .

Speaker #2: According to plan . We expect first power before the end of the year and the project is expected to be commissioned towards the end of Q1 2026 .

Speaker #2: For Hornsea Three in the U.K. . Construction is progressing well . The onshore works at the landfall cable route and converter stations have progressed in line with the schedule since last quarter .

Speaker #2: For the offshore scope , the project will be using two HVDC offshore converter stations . The first platform is undergoing final equipment installation in Norway , which is progressing well , and the second platform completed its scope in Thailand and is currently in transit to Norway to complete the same final works .

Rasmus Errboe: The first platform is undergoing final equipment installation in Norway, which is progressing well. The second platform completed its scope in Thailand and is currently in transit to Norway to complete the same final works. We have continued with the offshore activities where we completed the removal of unexploded ordinances across the whole site during Q3. We continue to closely monitor a number of items related to the delivery of the project. This includes the installation schedule of the project's grid connection, where we are working closely with National Grid on our onshore grid connection works to support planning of our commissioning next year. Further, we continue to focus on manufacturing of turbine monopile foundations to ensure it is delivered according to plan, enabling us to commence installation in 2026. The manufacturing has started as planned, and there are multiple suppliers contracted for the scope.

Speaker #2: We have continued with the offshore activities where we completed the removal of unexploded ordnance across the whole site during the third quarter . We continue to closely monitor a number of items related to the delivery of the project .

Speaker #2: This includes the installation schedule of the project's grid connection , where we are working closely with National Grid on our onshore grid connection works to support planning of our commissioning next year .

Speaker #2: Further , we continue to focus on manufacturing of turbine Monopile foundations to ensure it is delivered according to plan , enabling us to commence installation in 2026 .

Speaker #2: The manufacturing has started as planned and there are multiple suppliers contracted for the scope and , if relevant , we can utilise the flexibility gained from this to to mitigate risks .

Rasmus Errboe: If relevant, we can utilize the flexibility gained from this to mitigate risks if they occur. Next steps in the project will be commencement of the main offshore installation activities in early 2026, which start with the installation of the offshore export cable, as well as monopile foundation installation. In Poland, our Baltica Two project is moving ahead according to schedule, and we are progressing the first phases of the construction work. In Q3, we have continued construction work at the onshore substation site, which includes the installation of the first part of the export cable. The manufacturing of turbine foundations is progressing well, with 22 completed so far. The manufacturing of the four offshore substations is progressing, and manufacturing of the offshore export cable started mid-October.

Speaker #2: If they occur . Next steps in the project will be commencement of the main offshore installation activities in early 2026 , which starts with the installation of the offshore export cable , as well as Monopile Foundation installation .

Speaker #2: In Poland . Our Baltika two project is moving ahead according to schedule and we are progressing . The first phases of the construction work .

Speaker #2: In the third quarter , we have continued construction work at the onshore substation site , which includes the installation of the first part of the export cable , the manufacturing of turbine foundations is progressing well with 22 completed so far .

Speaker #2: The manufacturing of the four offshore substations is progressing and manufacturing of the offshore export cables started mid-October . With this progress , the degree of completion for the project has increased to approximately 15% , up from 10% in Q2 .

Rasmus Errboe: With this progress, the degree of completion for the project has increased to approximately 15%, up from 10% in Q2. There are a number of items for the installation schedule that we are closely monitoring. This includes progress on the manufacturing of the four offshore substations and fabrication progress of the key components for onshore and offshore substations. We remain on track for earliest possible sail away mid-2026 from Vietnam for the four offshore substations. Progress on the turbine installation harbor in Poland is still on track. We are closely engaged with contractors and regulators to ensure that we progress according to the current schedule. Next steps are preparation of the seabed survey ahead of turbine foundation installation, which is planned to commence during mid-2026.

Speaker #2: There are a number of items for the installation schedule that we are closely monitoring . This includes progress on the manufacturing of the four offshore substations and fabrication progress of the key components for onshore and offshore substations .

Speaker #2: We remain on track for earliest possible sail away mid 2026 from Vietnam for the four offshore substations . Progress on the turbine installation harbour in Poland is still on track .

Speaker #2: We are closely engaged with contractors and regulators to ensure that we progress according to the current schedule . Next steps are preparing of preparation of the seabed survey ahead of turbine foundation installation , which is planned to commence during mid 2026 .

Speaker #2: Now turning to slide seven and a more detailed update on our Greater Changhua Tooby and four project in Taiwan . Overall , the installation of the remaining scopes of the project has made good progress during the quarter .

Rasmus Errboe: Now turning to slide 7, and a more detailed update on our Greater Changhua 2B and 4 project in Taiwan. Overall, the installation of the remaining scopes of the project has made good progress during the quarter. Greater Changhua 4 has commenced generation, and this will continue to ramp up as more turbines get energized during Q4 of this year. For Greater Changhua 2B, the damage to the export cable means that we will only be producing power again from mid-2026, once the damaged export cable has been replaced. Looking at installation during the quarter, we have made progress across several scopes. This includes the installation of turbines, where 58 turbines of the total 66 positions are now installed, and the rest are expected to be completed by end of 2025.

Speaker #2: Greater Changhua four has commenced generation and this will continue to ramp up as more turbines get energized during Q4 . Of this year .

Speaker #2: For Greater Changhua , two B the damage to the export cable means that we will only be producing power again from mid 2026 , once the damage export cable has been replaced .

Speaker #2: Looking at installation during the quarter , we have made progress across several scopes . This includes the installation of turbines where 58 turbines of the total 66 positions are now installed , and the rest are expected to be completed by end of 2025 .

Speaker #2: We have installed array cables for 50 of the 66 positions , and we have mobilised additional vessels during the quarter to strengthen the installation progress or process of the remaining cables .

Rasmus Errboe: We have installed array cables for 50 of the 66 positions, and we have mobilized additional vessels during the quarter to strengthen the installation progress or process of the remaining cables, as weather conditions are expected to be more challenging during the winter season. With progress achieved during the quarter, the project has now reached a degree of completion of approximately 65%, up from 55% in Q2. The focus of the project remains on installation of remaining turbines and array cables, as well as replacing the export cable for the Greater Changhua 2B section. Turning to slide 8, and an update on our Northeast program, starting with Revolution Wind.

Speaker #2: As weather conditions are expected to be more challenging during the winter season , with progress achieved during the quarter , the project has now reached a degree of completion of approximately 65% , up from 55% in Q2 .

Speaker #2: The focus of the project remains on installation of remaining turbines and array cables , as well as replacing the export cable for the Greater Changhua to be section .

Speaker #2: Turning to slide eight and an update on our northeast programme , starting with Revolution Wind . During the quarter , the project has made good progress as we have completed both the installation of the replacement Monopile for the second offshore substation , as well as the installation of the offshore substation itself , such that both of the project's two offshore substations are now installed on turbine installation .

Rasmus Errboe: During the quarter, the project has made good progress as we have completed both the installation of the replacement monopile for the second offshore substation, as well as the installation of the offshore substation itself, such that both of the project's two offshore substations are now installed. On turbine installation, we continue to make progress, as we have now installed 52 of the 65 turbines for the project, and array cable installation has commenced and is progressing well. With progress achieved during the quarter, the project has now reached a degree of completion of approximately 85%, up from 80% in Q2. The project continues to progress on a number of scopes that are critical to the delivery of the current schedule. For the onshore substation, we are continuing to progress construction activity according to the current schedule.

Speaker #2: We continue to make progress as we have now installed 52 of the 65 turbines for the project and array cable installation has commenced and is progressing well .

Speaker #2: With progress achieved during the quarter , the project has now reached a degree of completion of approximately 85% . Up from 80% in Q2 .

Speaker #2: The project continues to progress on a number of scopes that are critical to the delivery of the current schedule for the onshore substation .

Speaker #2: We are continuing to progress construction activity according to the current schedule , we remain on site to manage the continued installation of the project and expect energisation of the onshore substation early next year .

Rasmus Errboe: We remain on site to manage the continued installation of the project and expect energization of the onshore substation early next year. For turbine installation, we will continue to monitor the installation rate closely as we enter into the winter season, where weather conditions impact speed of the installation rate. First power is expected during first half of 2026, and the project remains on track for commissioning in the second half of 2026. Now turning to slide 9 and our Sunrise Wind project, where we have also continued to see good progress across the different scopes. We have completed the installation of the project's single offshore converter station in September and continued the installation of turbine foundations with 50, sorry, 44 of the 84 positions installed now.

Speaker #2: For turbine installation , we will continue to monitor the installation rate closely as we enter into the winter season , where weather conditions impact speed of the installation rate .

Speaker #2: First power is expected during first half of 2026 , and the project remains on track for commissioning in the second half of 2026 .

Speaker #2: Now turning to slide nine and our sunrise Wind project , where we have also continued to see good progress across the different scopes we have completed .

Speaker #2: The installation of the projects single offshore converter station in September and continued the installation of turbine foundations with 50 sorry 44 of the 84 positions installed now .

Speaker #2: This work will soon be paused as planned due to time of year restrictions of wind turbine foundations can be installed and will be resumed when next installation season starts in the spring .

Rasmus Errboe: This work will soon be paused as planned due to time of year restrictions of when turbine foundations can be installed and will be resumed when next installation season starts in the spring. The turbine installation will commence following completion of turbine installation Revolution Wind. For the onshore substation, the commissioning works are progressing according to plan with installation of nearshore section of the export cable expected in the coming months. With progress achieved during the quarter, the project has now reached a degree of completion of approximately 40% up from 35% in Q2. The focus remains on the items that are critical to delivery on the current schedule. The fabrication of remaining turbine foundations is progressing according to plan, and we expect to have all remaining turbine foundations completed by the end of the year.

Speaker #2: The turbine installation will commence following completion of turbine installation . Revolution wind and for the for the onshore substation . The commissioning works are progressing according to plan , with installation of near-shore section of the export cable expected in the coming months , with progress achieved during the quarter .

Speaker #2: The project has now reached a degree of completion of approximately 40% , up from 35% in Q2 . The focus remains on the items that are critical to delivery on the current schedule .

Speaker #2: The fabrication of remaining turbine foundations is progressing according to plan , and we expect to have all remaining turbine foundations completed by the end of the year .

Speaker #2: On the export cable we have completed the final factory acceptance tests for majority of the sections with the final ones expected to be completed by end of the year , and we will start the installation of the near-shore section at the end of this year as well .

Rasmus Errboe: On the export cable, we have completed the final factory acceptance tests for majority of the sections, with the final ones expected to be completed by end of the year. We will start the installation of the nearshore section at the end of this year as well. We continue to manage the risks related to the installation of the project, we remain on track for commissioning in the second half of 2027. With this, let me hand over the word to you, Trond.

Speaker #2: We continue to manage the risks related to the installation of the project, and we remain on track for commissioning in the second half of 2027.

Speaker #2: With this, let me hand over the word to you, Todd.

Speaker #5: Thank you . Rasmus , and good afternoon , everyone . As always , unless I state otherwise , the numbers I refer to will be in Danish kroner .

Trond Westlie: Thank you, Rasmus, and good afternoon, everyone. As always, unless I state otherwise, the numbers I refer to will be in Danish kroner. Before covering the Q3 development, let's go to slide 11. I want to start with our announcement from Monday, as we have entered into an agreement with Apollo to divest 50% stake in our 2.9 gigawatt Hornsea Three offshore wind farm in the UK. The transaction balances the key objectives for partnerships and divestments with an emphasis on capital management and represents a major milestone in our funding plan. The transaction supports a further strengthening of our capital structure and ensures significant progress on our partnership and divestment program. The total value of the transaction is approximately DKK 39 billion, and around DKK 20 billion of the total transaction value will be paid upon closing of the transaction.

Speaker #5: So, before covering the third quarter development, let's go to slide 11. And I want to start with our announcement from Monday.

Speaker #5: As we have entered into an agreement with Apollo to divest 50% stake in our 2.9GW Hornsea Three offshore wind farm in the UK .

Speaker #5: The transaction balances the key objectives for partnerships and divestments , with an emphasis on capital management and represents a major milestone in our funding plan .

Speaker #5: The transaction supports a further strengthening of our capital structure and ensures significant progress on our partnership and divestment programme . The total value of the transaction is approximately 39 billion and around 20 billion of the total transaction value will be paid upon closing of the transaction .

Speaker #5: The remaining amount is expected to be paid under the construction agreement . Upon achievement of certain construction milestones . In terms of our targeted proceeds , or more than 35 billion across 25 and 26 , it is the 10 billion received under the SBA agreement , which counts towards this target .

Trond Westlie: The remaining amount is expected to be paid under the construction agreement upon achievement of certain construction milestones. In terms of our targeted proceeds, or more than DKK 35 billion across 2025 and 2026, it is the DKK 10 billion received under the SPA agreement which counts towards this target. The total transaction value covers the acquisition of 50% equity stake, equity share, sorry, and the commitment from the partner to fund 50% of the payment under the EPC contract for the wind farm and the offshore transmission costs as. The up from non-cash EBITDA effect of the transaction is in line with the expectation outlined in the prospectus of the recently completed rights issue and including the other aspects of the transaction, such as the expected earnings under the construction agreement and service contract between Ørsted and the project.

Speaker #5: The total transaction value covers the acquisition of 50% equity stake , equity share ownership . Share . Sorry . And the commitment from the partner to fund 50% of the payment under the EPC contract for the wind farm and the Offshore transmission costs .

Speaker #5: As . The upfront non-cash EBITDA effect of the transaction is in line with the expectation outlined in the prospectus of the recently completed rights issue and including the other aspects of the transaction , such as the expected earnings under the construction agreement and service contract between Erstad and the project .

Speaker #5: The expected EBITDA impact of the transaction is broadly neutral over the lifetime of the project . With that , let's turn to slide 12 and the EBITDA for the quarter .

Trond Westlie: The expected EBITDA impact of the transaction is broadly neutral over the lifetime of the project. With that, let's turn to slide 12 and the EBITDA for the quarter. In Q3, we realized an EBITDA of DKK 3.1 billion. Let me walk you through the main developments for the quarter. For our offshore business, the overall earning came in at DKK 2.2 billion. The earnings from sites decreased, driven by lower wind speeds and stepped down in subsidy levels from all the wind farms, as well as lower power trading units. This was partly offset by full contribution at Gode Wind 3, compensation for Borkum Riffgrund 3, and higher availability rates across the portfolio. Earnings on existing partnership decreased as a result of updated costs for array cable installation for Greater Changhua 4.

Speaker #5: In third quarter , we realized an EBITDA of 3.1 billion . Let me walk you through the main developments for the quarter for our offshore business .

Speaker #5: The overall earnings came in at 2.2 billion . The earnings from sites decreased , driven by lower wind speeds and stepped down in subsidy levels from all the wind farms , as well as lower power trading , power trading earnings .

Speaker #5: This was partly offset by full contribution at Goodwin three . Compensation for Borgen three and higher availability rates across the portfolio . Earnings on existing partnership decreased as a result of updated costs for array cable installation .

Speaker #5: For Greater Changhua , for . Over the summer , there were challenges with challenging weather conditions , including typhoon , which slowed down our planned installation speed .

Trond Westlie: Over the summer, there were challenges, challenging weather conditions, including a typhoon which slowed down our planned installation speed. As a result, we have, during Q3, strengthened our setup for the installation of the remaining array cables by mobilizing additional vessels. This has led us to revise the earnings that we expect under the construction agreement. As communicated earlier, we did not anticipate any material earnings under the construction agreement. Taking into account the strengthening of the installation setup and costs relating to extending the installation period leads to an impact in our accounts. Following this revision, the business case continued to have a comfortable headroom. Other costs, which includes unallocated overhead and fixed costs, as well as expensed project development costs, increased compared to last year, in line with our expectation.

Speaker #5: As a result , we have during third quarter strengthened our setup for the installation of the remaining array cables by mobilizing additional vessels .

Speaker #5: This has led us to revise the earnings that we expect under the construction agreement . As communicated earlier , we did not anticipate any material earnings under construction agreement , so taking into account the strengthening of the installation setup and costs relating to extending the installation period leads to an impact in our accounts .

Speaker #5: Following this revision , the business case continued to have a comfortable headroom . Other costs which includes unallocated overhead and fixed costs , as well as expensed project development costs , increased compared to last year in line with our expectation , part of the increase is driven by a change in our cost allocation methodology and does not impact the total EBITDA .

Trond Westlie: Part of the increase is driven by a change in our cost allocation methodology and does not impact the total EBITDA. This cost reallocation is reflected in our full year guidance for 25. For onshore, the EBITDA decreased by approximately DKK 200 million, primarily driven by lower wind speeds, which were partly offset by ramp up generation from new assets. Within bioenergy and other, earnings from our combined heat and power plants were higher than last year, driven by higher power prices. Earnings in our gas business increased slightly, driven by higher offtake volumes. We did not enter into any new partnerships in Q3 of 25. Let's turn to slide 13. In Q3, total impairments amounted to DKK 1.8 billion.

Speaker #5: This cost reallocation is reflected in our full year guidance for 25 . For onshore , the Epta decreased by approximately 200 million , primarily driven by lower wind speeds , which were partly offset by ramp up generation from new assets .

Speaker #5: Within bioenergy and other earnings from our combined heat and power plants were higher than last year , driven by higher power prices . Earnings in our gas business increased slightly , driven from driven by higher offtake volumes .

Speaker #5: We did not enter into any new partnerships in the third quarter of 25 . Let's turn to slide 13 . In the third quarter , total impairments amounted to 1.8 billion .

Speaker #5: The impairments primarily relate to our US offshore projects and are driven by higher tariffs and increased costs . As a result of the stop work order for for revolution wind partly offset by decrease in long dated US interest rates .

Trond Westlie: The impairments primarily relate to our US offshore projects and are driven by higher tariffs and increased costs as a result of the stop work order for Revolution Wind, partly offset by decrease in long-dated US interest rates. The impairment related to higher tariffs amount to $two and a half billion, in line with the range that was included in the prospectus re-released in connection with the rights issue. This amount reflects recent changes to the US trade policies, including the increased tariffs on steel and aluminum. The impairment related to the stop work order amount to $500 million and is also in line with estimates that was included in the prospectus in connection with the rights issue. This reflects the higher cost for both Revolution Wind and Sunrise Wind due to extension contracts needed to complete the installation of the projects.

Speaker #5: The impairment related to higher tariffs amount to 2.5 billion , in line with the range that was included in the prospective released in connection with the rights issue .

Speaker #5: This amount reflects recent changes to the US trade policies , including the increased tariffs on steel and aluminium . The impairment related to the stop work order amounted to 500 million and is also in line with estimates that was included in the prospectus in connection with the rights issue .

Speaker #5: This reflects the higher cost for both Revolution Wind and Sunrise Wind due to extension contracts needed to complete the installation of the projects .

Speaker #5: These effects are partly offset by a reversal of 1.3 billion due to the decrease in long , long dated US interest rates , leading to lower WACC .

Trond Westlie: These effects are partly offset by a reversal of DKK 1.3 billion due to the decreased in long-dated US interest rates, leading to lower WACC level across our US offshore and onshore projects. Our net profit for the quarter totaled a negative DKK 1.7 billion and was impacted by both the decreased earnings as well as the impairments. In Q3 2024, net profit amounted to DKK 5.2 billion, of which DKK 5.1 billion were related to a reversal of a provision related to Ocean Wind. Adjusted for impairments and cancellation fees, our return on capital employed came in at 10.2%, which was decreased compared to last year, driven by the higher capital employed. The reported ROCE came in at 2% and was impacted by the impairments recognized over the last 12 months.

Speaker #5: Level across our US offshore and onshore projects . Our net profit for the quarter totaled a negative 1.7 billion , and was impacted by both the decreased earnings as well as the impairments in Q3 24 net profit amounted to 5.2 billion , of which 5.1 billion were related to a reversal of the provision related to ocean wind .

Speaker #5: Adjusted for impairments and cancellation , fees are return on capital employed came in at 10.5 10.2% , which was a decrease compared to last year , driven by the higher capital employed .

Speaker #5: The reported RoCE came in at 2% and was impacted by the impairment recognized over the last 12 months . Let's turn to slide 14 and our net interest bearing debt and credit metrics .

Trond Westlie: Let's turn to slide 14 and our net interest-bearing debt and credit metrics. At the end of Q3 2025, our net debt amounted to DKK 83 billion, an increase of approximately DKK 16 billion during the quarter. The increase was predominantly driven by gross investments of DKK 15 billion into the construction of our new renewable project portfolio. The contribution from of our operating earnings in our cash flow from operating activities was more than offset by costs relating to the construction of transmission assets in the UK, as well as seasonally in other working capital items. This was also the case for the same quarter last year. As the right issue was completed on 9 October 2025, the proceeds of approximately DKK 60 billion will accordingly be reflected in our accounts by full year.

Speaker #5: At the end of Q3 25 , our net debt amounted to 83 billion , an increase of approximately 16 billion during the quarter .

Speaker #5: The increase was predominantly driven by gross investments of $15 billion into the construction of our new renewable project portfolio. The contribution from our operating earnings in our cash flow from operating activities was more than offset by costs relating to the construction of transmission assets in the UK, as well as seasonally in other working capital items.

Speaker #5: This was also the case for the same quarter of last year . As the rights issue was completed on 9th of October 25 , the proceeds of approximately 60 billion will accordingly be reflected in our accounts by full year .

Speaker #5: Also, subject to the closing of the transaction before the end of the year, the proceeds from the Hornsea Three transaction will likewise be included in the net debt numbers.

Trond Westlie: Also, subject to the closing of the transaction before the end of the year, the proceeds from the Hornsea 3 transaction will likewise be included in the net debt numbers. Finally, the project financing package for Greater Changhua 2 were closed in July, yet had no impact on net debt, as the proceeds received were matched by a corresponding increased debt. Upon closing of the planned equity divestment of the project, the asset and associated project financing package is planned to be deconsolidated, which will then have an impact on the net debt position. For credit metric, FFO to adjusted net debt stood approximately at 14% at the end of Q3, which is a slight decrease compared to the previous quarter.

Speaker #5: Finally , the project financing package for Greater Changhua two were closed in July , yet had no impact on net debt as the proceeds received were matched by a corresponding increased debt .

Speaker #5: Upon closing of the planned equity divestment of the project, the asset and associated project financing package is planned to be deconsolidated, which will then have an impact on the debt.

Speaker #5: Debt position . Our credit metric , FFO , to adjusted net debt stood approximately at 14% at the end of the third quarter , which is a slight decrease compared to a the previous quarter .

Speaker #5: The higher funds from operations in the 12 months rolling period was offset by the increase in adjusted net debt . The metric will expectedly increase to well above target of 30% to 30% in the next quarter , as the incoming proceeds from the rights issue and closing on the horsey three transaction will be reflected in our accounts .

Trond Westlie: The higher funds from operation in the 12-month rolling period was offset by the increase in adjusted net debt. The metric will expectedly increase to well above target of 30% in the next quarter as the incoming proceeds from the rights issue and closing on the Hornsea 3 transaction will be reflected in our accounts. Finally, let's turn to slide 15 and look in our outlook for 2025. With our solid operational performance for the first nine months and heading into a quarter with seasonal higher wind speeds, we reiterate our full year EBITDA guidance, excluding new partnership and cancellation fees of DKK 24 to 27 billion. We also maintain our gross investment guidance for 2025 of DKK 50 to 54 billion. The gross investment guidance is sensitive to milestone payments being moved between years and the level of tariffs.

Speaker #5: And finally , let's turn to slide 15 and look in our outlook for 25 . With our solid operational performance for the first nine months and heading into a quarter with seasonal higher wind speeds , we reiterate our full year EBITDA guidance excluding new partnership and cancellation fees of 24 to 27 billion .

Speaker #5: We also maintain our gross investment guidance for 25 of 50 to 54 billion . The gross investment guidance is sensitive to milestone payments being moved between years and the level of tariffs .

Speaker #5: We continue to follow the development regarding potential tariffs and other regulatory changes , particularly affecting the US and are continuous , continually assessing any possible financial and wider impacts .

Trond Westlie: We continue to follow the development regarding potential tariffs and other regulatory changes, particularly affecting the US and are continually assessing any possible financial and wider impacts. With that, we will now open for question. Operator, please.

Speaker #5: So with that , we will now open for questions . Operator please .

Speaker #1: This concludes the presentation and we will now open for questions . This call will have to end no later than 1530 . Please respect only one question per participant .

Operator: This concludes the presentation and we will now open for questions. This call will have to end no later than 3:30PM. Please respect only one question per participant and then you can go back to the queue for a second question. The first question comes from the line of Christian Tønnesen from SEB. Please go ahead.

Speaker #1: And then you can go back to the queue for a second question . The first question comes from the line of Christian Tornou from CIB .

Speaker #1: Please go ahead .

Speaker #6: Yes . Thank you so my question is about the expected lifetime of your offshore wind assets . So with the on the three transaction , the other day , I understand you are looking at up to to 35 year lifetime of of this asset .

Christian Tønnesen: Yes, thank you. My question is about the expected lifetime of your offshore wind assets. On the three transaction the other day, I understand you are looking at up to a 35-year lifetime of this asset. Previously you've been talking more to a 25-year lifetime of your offshore wind assets, which at least what I've been using in my model. My question is essentially what would be the appropriate lifetime we should apply to our valuation of your offshore assets?

Speaker #6: So previously you've been been talking more to a 25 year lifetime of , of your of your wind assets , which what I've been using in my model .

Speaker #6: So my question is essentially, what would be the appropriate lifetime we should apply to our valuation of your offshore assets?

Speaker #5: Well , on on the on the lifetime of the capitalized investments that we have from the starting point , we do use just short of a 25% year depreciation .

Speaker #5: Well , on on the on the lifetime of the capitalized investments that we have from the starting point , we do use

Trond Westlie: Well, on the lifetime of the capitalized investments that we have from the starting point, we do use just short of a 25% year depreciation. The economic value of that is of course, we use the short of 25 yard years depreciation. When it comes to the business case as such and the lease period, that is sort of a different aspect, and that's what is included in the agreement that we have been clear, very transparent about with Apollo. That of course the lease is a long period.

Speaker #5: . Depreciation when it comes to the business case . As such . And the lease period that is sort of a different aspect .

Speaker #5: And that's what is included in the agreement that we have been clear , very transparent about with Apollo and that , of course , the lease is a long period and as a result of that , the business case at least longer than the economic value that we capitalized as a start , basically due to maintenance programs , repowering possibilities and so forth , relative to the long lease of the the area .

Trond Westlie: As a result of that, the business case is of course longer than the economic value that we capitalize as a start, basically due to maintenance programs, repowering possibilities and so forth relative to the long lease of the area. That you have to probably distinguish between how we capitalize, how we depreciate and also how we actually see the business case.

Speaker #5: So that you have to probably distinguish between how we capitalize , how we depreciate , and also how we actually see the business case .

Speaker #1: The next question comes from the line of Harry Weber from BNP Paribas . Please go ahead .

Operator: The next question comes from the line of Harry Wyburd from BNP Paribas. Please go ahead.

Speaker #7: Hi . Thanks . Afternoon , everyone . So can I focus on on the three sell down . So thank you for the call yesterday where you educated us a bit about the cash flow profiling .

Harry Wyburd: Hi. Thanks. Afternoon, everyone. Can I focus on the Hornsea three sell down? Thank you for the call yesterday where you educated us a bit about the cash flow profiling. My question is, given that Apollo have the rights to the majority of the cash flow during the CFD period, and given that you have the majority to the rights to the cash flows after that, have we opened up a new thread of book value risk or volatility here? Because presumably you might review though the NPV of those cash flows from time to time, depending on discount rates and also your future reversion power price assumptions for the project. Is this something where we should expect some book value updates on a quarterly basis going forward?

Speaker #7: My question is , given that Apollo have the right to the majority of the cash flow during the CFD period , and given that you have the majority to the rights of the cash flows after that , have we opened up a new thread of book value risk or volatility here ?

Speaker #7: Because presumably you you might review the NPV of those cash flows from time to time , depending on discount rates and and also your future reversion power price assumptions for the project .

Speaker #7: So is this something we should expect some some book value updates on a quarterly basis going forward ? And if so , can you give us any kind of sense as to how material those changes might be relative to the other sort of impairment ?

Harry Wyburd: If so, can you give us any kind of sense as to how material those changes might be relative to the other sort of impairment pluses and minuses that you typically put through over the quarter? Then an allied question. When we're modeling cash flow, you know, we're all looking to 2028 when you've got all these projects up and running and perhaps now that the rights issue process is over, maybe you could throw in a bit of a guide for what 2028 EBITDA guidance might be, given that's really the key year when everything's up and running. Should we apply a haircut to that for cash flow, given that as I understand it, the majority of the cash flows in that year would be going to Apollo? Thank you.

Speaker #7: Pluses and minuses that you typically put through over the quarter ? And then an allied question when we're modeling cash flow , you know , we're all looking to 2028 when you call these projects up and running .

Speaker #7: And perhaps now that the rights issue process is over , maybe you could throw in a bit of a guide for , what , 2028 EBITDA guidance might be given ?

Speaker #7: That's really the key year when everything's up and running . But should we apply a haircut to that for cash flow , given that , as I understand it , the majority of the cash flows in that year would be going to Apollo .

Speaker #7: Thank you .

Trond Westlie: Well, let's take the first one first. When it comes to the sort of the uncertainty of the fluctuations on the starting point of the provision that we actually do going forward on the sort of asymmetry, yes, it is correct that we have to evaluate that every quarter. Those evaluation will come as today's rules in IFRS. Those adjustments will come under the financial income line. Second part of this is of course that since we have both a payable and a receivable in this, there is an incorporated hedge as a result of that in addition. I would not, in essence, yes, there will be elements to this being sort of adjusted every quarter. We do not expect that to be significant, and we are presenting that under IFRS rules today.

Speaker #5: Then well , let's take the first one first . When it comes to the the sort of the uncertainty of the fluctuations on the starting point of the provision that we actually do going forward on the sort of asymmetry .

Speaker #5: Yes , it is correct that we have to evaluate that every quarter , those evaluation will come as today's rules in IFRS , those adjustments will come under the financial income line .

Speaker #5: Second part of this is , of course , that since we have both payable and receivable this , there is an in incorporated hedge .

Speaker #5: As a result of that , in addition . So I would not and so in essence , yes , there will be elements to this being sort of adjusted every quarter .

Speaker #5: We do not expect that to be significant . And we are presenting that under IFRS rules today , it will come in under the financial line .

Trond Westlie: It will come under the financial line.

Speaker #5: On the outlook okay . Thank you . On the outlook , on the outlook , sorry of 28 . We will not do an update on the 28 expectations .

Rasmus Errboe: On the outlook.

Harry Wyburd: Okay. Thank you.

Rasmus Errboe: On the outlook, sorry, of 2028, we will not do an update on the 2028 expectations so soon after the right issue and the prospectus that we issued. We will, of course, come more back to that and be more granular when we come to the yearly updates in February.

Speaker #5: So soon after the rights issue . And the prospectus that we issued , we will of course come more back to that and be more granular when we come to the yearly updates in February .

Speaker #7: Okay . Thank you . And the comment on the on on the cash flow haircut , I think actually in the first years of the project , I think for three years it was 5050 and then thereafter it reverts to 7030 and Apollo's favor .

Harry Wyburd: Okay. Thank you. The comment on the cash flow haircut, I think actually in the first years of the project, I think it was 3 years, it was 50/50, thereafter it reverts to 70/30 in Apollo's favor. Should we be making a cash flow adjustment? Is that how we should be thinking about it? We'd need to reduce a little the EBITDA you report on a proportional basis to reflect the fact that you're getting less of the cash flows in the short term. Is that the right way to think about it?

Speaker #7: But should we be making a cash flow adjustment ? Is that how he should be thinking about it ? We we need to reduce a little the EBITDA .

Speaker #7: You report on a proportional basis to reflect the fact that you're getting less of the cash flows in the short term . Is that the right way to think about it ?

Speaker #5: Well , the that's going to be the difference between the the PNL and the EBITDA PNL and the cash flow statement . So the of course , in the in .

Rasmus Errboe: Well, that's going to be the difference between the P&L, the EBITDA, P&L, and the cash flow statement. Of course, in the P&L statement, that will of course, and the adjustment that we're making right there, the loss adjustment we're making right now, will of course be reversed under the EBITDA. Of course, in our operational cash flow statement, we'll of course address that and be very co-specific of the non-cash elements within it.

Speaker #5: The PNL statement , that will , of course , and the adjustment that we're making , right , the loss adjustment we're making right now will , of course , be reversed under the FDA .

Speaker #5: But of course , in our operational cash flow statement , we'll of course address that and be very specific of the non-cash elements within it .

Speaker #7: Okay . Thank you very much .

Harry Wyburd: Okay. Thank you very much.

Speaker #1: We now have a question from the line of Dominik Ness from Barclays . Please go ahead .

Operator: We now have a question from the line of Dominic Nash from Barclays. Please go ahead.

Speaker #8: Hi there .

Dominic Nash: Hi there. Good morning. Good afternoon even. Couple of questions, please. The first one is on utilization levels of your offshore wind. You always quote output. I believe you don't give us an update on the actual potential output pre-curtailment. I was just wondering what sort of level of curtailment are you sort of seeing in your offshore fleet, and what would that do if we were to adjust for sort of like the proper underlying output capability? The second question, it's a simple one here. Dividend policy. You've not given any sort of firm numbers yet. I think it's 2026, you're going to start paying a dividend. Consensus, I think, in Bloomberg is 4 DKK a share. Are you happy with that consensus number? Thank you.

Speaker #9: Good morning . Good afternoon . Evening . A couple of questions , please . One should be quite quite quick . But the first one is on utilization levels of your offshore wind .

Speaker #9: You always quote output . But I believe you don't give us an update on the actual potential output pre curtailment . And I was wondering what sort of level of curtailment are you seeing in your offshore fleet .

Speaker #9: And what would that do if we were to adjust for sort of like the sort of proper underlying output capability . And the second question is a simple one here .

Speaker #9: Dividend policy . You've got you've not given any sort of firm numbers yet . I think it's 2026 . You're going to start paying a dividend consensus I think in Bloomberg is four krona a share .

Speaker #9: Are you happy with that consensus number ? Thank you .

Speaker #2: Thank you . Thank you . Dominik . On on the sort of the the utilization levels that you talk about . We we don't we don't guide on on specific curtailment of our of our offshore wind farms onshore , offshore curtailment of any nature .

Rasmus Errboe: Thank you. Thank you, Dominic. On the sort of the utilization levels that you talk about, we don't guide on a specific curtailment of our offshore wind farms, of onshore, offshore curtailment of any nature. We what you can see is that we have delivered a very solid availability performance during the year. 93% park, or sorry, production-based availability for the first nine months and 94% for Q3. Therefore, I'm very pleased with the underlying performance, but we don't guide on the curtailment levels. Also just reminding you that there are different frameworks in different countries for a curtailment.

Speaker #2: We we what you can see is that we have delivered very solid availability performance during the year . 93% or sorry production based availability for the first nine months .

Speaker #2: And and 94% for for Q3 . So so therefore I'm very , very pleased with the underlying performance . But we don't guide on the on the curtailment levels .

Speaker #2: And also just just reminding you that that that there are different different frameworks in different countries for curtailment . And as an example , in , in Germany we are we are compensated for for the vast majority of curtailments from , from the onshore grid as , as , as , as for the dividend policy .

Rasmus Errboe: As an example, in Germany, we are compensated for the vast majority of curtailments from the onshore grid. As for the dividend policy, we have confirmed for a while now that we expect to pay out a dividend again by 2027 for accounting year 2026. We will stick to that, but we will not comment on the level of the dividend.

Speaker #2: We we have confirmed for for a while now that we expect to to pay out dividends again by 2027 for accounting year 26 , we will we will stick to that , but we will not comment on the level of the dividend .

Speaker #9: Okay . Thank you .

Dominic Nash: Okay. Thank you.

Speaker #1: The next question comes from the line of Mark Freshney from UBS . Please go ahead .

Operator: The next question comes from the line of Mark Freshney from UBS. Please go ahead.

Speaker #10: Thank you very much . Rasmus . If I could pick you up on some comments you made about a month ago at a conference , you mentioned that there were two tracks to managing the stop order on Revolution .

Mark Freshney: Thank you very much. Rasmus, if I could pick you up on some comments you made about a month ago at a conference. You mentioned that there were two tracks to managing the stop order on Revolution. There was the legal track, and there was the negotiated settlement, the dialogue track. Clearly, there was your big shareholder announce some deals with the US Department of Defense. Clearly a negotiated settlement that would protect Sunrise and Revolution would always be preferable to a winning in court. Can you make any comments on how that, those negotiations may be proceeding?

Speaker #10: There was the legal track and there was the negotiated settlement . The dialogue track . Clearly , there were your big shareholder announced some some deals with the US Department of Defense , clearly a negotiated settlement that would protect sunrise and revolution would always be preferable to a winning in court .

Speaker #10: So can you . Can you make any comments on on how that those negotiations may be , may be proceeding ?

Speaker #2: Hi . Hi , Mark . Thank you very much . You are right . We are pursuing two tracks . One is the the legal track where we received the injunction on the 22nd of September that allowed us to go back to work .

Rasmus Errboe: Hi. Hi, Mark. Thank you very much. You are right. We are pursuing two tracks. One is the legal track, where we received the injunction on 22 September that allowed us to go back to work. The other track is a dialogue track with the relevant people in the administration. It is not sort of my approach, Mark, to this is the same as it has been all along, and that is that I don't go into details about the conversations that we may or may not have in terms of making a deal.

Speaker #2: And then the other track is a dialogue track with , with with the , with the relevant people in the , in the administration .

Speaker #2: I it is not my approach , Mark to this is the same as it has been all along , and that is that I don't don't go into details about about the conversations that we may or may not have in terms of , of , of making , making a deal .

Speaker #2: Our focus is to get get to a you can say , a complete solution for , for , for revolution , where we still have the stop work order claim outstanding .

Rasmus Errboe: Our focus is to get to a, you can say, complete solution for Revolution Wind, where we still have the stop work order claim outstanding. Our focus is on the projects, and I am pleased with the progress that we have seen in terms of construction across both Revolution Wind and Sunrise. Where we have seen the degree of completion increasing from 80 to 85 on Revolution Wind and from 35 to 40 on Sunrise Wind, including the installation of all the substation. That is really where we have our focus.

Speaker #2: Our focus is on the projects . And I am pleased with the progress that we have seen in terms of construction on across both Revolution Wind and Sunrise , where we have seen that we have completion increasing from from 80 to 85 on Revolution Wind and from 35 to 40 on Sunrise wind , including the installation of all the substations .

Speaker #2: So that is really where we have our focus .

Speaker #10: Thank you . I respect that , and if I may have a follow up just on the credit rating , I mean , I think S&P we're waiting for the transaction that we saw yesterday .

Mark Freshney: Thank you. I respect that. If I may have a follow-up just on the credit rating. I mean, I think S&P were waiting for the transaction that we saw yesterday. Can we expect some news on the rating? Does your modeling suggest that the Hornsea Three farm down gets you where you need to be on that S&P tripwire, so to speak?

Speaker #10: Can we expect some news on the rating and does your modeling suggest that that the Hornsea Three farm down gets you gets you where you need to be on that that S&P tripwire , so to speak ?

Trond Westlie: Well, Mark, we are aware of the comments or the statements that S&P made in their update on their rating in August. Of course, we expect them to be more comfortable as a result of having managed to actually sign this agreement and basically following our timeline, as both signing and closing before year-end. Hopefully, it will have some effects. We are a bit uncertain about the interpretation evaluations of S&P, because they are sort of the odd man out in the three ratings that we do have. We just have to refer that sort of evaluation to them, Mark. I'm sorry.

Speaker #5: Well , Mark , we are aware of the comments or the statements that S&P made in their update on their rating in August .

Speaker #5: Of course , we expect them to be more comfortable as a result of having managed to actually sign this agreement . And basically following our timeline as both signing and closing before year end .

Speaker #5: So hopefully it will have some effects . We are a bit uncertain about the interpretation of evaluations of S&P because they are sort of the odd man out in the three ratings that we do have .

Speaker #5: So we just have to refer that sort of evaluation to Denmark . I'm sorry .

Speaker #10: Thank you very much . Thank you .

Mark Freshney: Thank you very much. Thank you.

Speaker #1: We now have a question from the line of Alberto Gandolfi from Goldman Sachs . Please go ahead .

Operator: We now have a question from the line of Alberto Gandolfi from Goldman Sachs. Please go ahead.

Speaker #11: Thank you so much for taking my question . I guess the first part is perhaps more for Trump than perhaps the second . For Rasmus .

Alberto Gandolfi: Thank you so much for taking my question. I guess the first part is perhaps more for Trond and perhaps second for Rasmus. It's on capital structure and capital allocation. The first part of the question is, you know, following the DKK 20 billion you're going to receive from the transaction and the amount this week and the rights issue, you know, technically at the nine months, you're basically debt-free. Of course, the company remains cash flow negative. I guess my question, the first part of the question is your balance sheet now fully de-risked? Is there any scenario where you see the risk of having to implement incremental measures to avoid a downgrade to junk? I'm just thinking, for instance, if the US project never start, can we say that even in that scenario, your balance sheet is now okay?

Speaker #11: It's on capital structure and capital allocation . So the first part of the question is , you following the 20 billion you're going to receive from the transaction and you announced this week and the rights issue , you know , technically at the nine months , you're basically debt free .

Speaker #11: And of course , the company remains cash flow negative . But I guess my question , the first part of the question is , is your balance sheet now fully derisked ?

Speaker #11: And is there any scenario where you see the risk of having to implement incremental measures to avoid downgrade to junk ? I'm just thinking , for instance , if the US project never start , can we say that even in that scenario , your balance sheet is now okay and and the second part of the question is that if you if you can elaborate on the first , I guess , then the question would be if the US projects start to contribute , then you could say that in 28 , your FFO to net debt is incredibly strong .

Alberto Gandolfi: The second part of the question is that if you can elaborate on the first, I guess, then the question would be if the US project start to contribute, then you could say that in 2028, your FFO to net debt is incredibly strong. Can you tell us how you are beginning to work for the repositioning of Ørsted at that point in time? What's your priority? Is organic growth at that point? Because you need to start winning awards in the next 12, 18, 24 months, I guess. Is it more wait-and-see to see what happens in the United States? Thank you.

Speaker #11: So can you tell us how you are beginning to work for the repositioning of Orsted at that point in time ? What's your priority is organic growth at that point ?

Speaker #11: Because you need to start winning awards in the next 12 , 18 , 24 months . I guess , or is it more wait and see to see what happens in the United States ?

Speaker #11: Thank you .

Speaker #5: Well , take the first one on capital structure . I think your numbers is fairly correct relative to where we are and where we're going to be at year end .

Trond Westlie: We'll take the first one on capital structure. I think your numbers is fairly correct relative to where we are and where we're gonna be at year-end. In starting to say that, of course, a lot of the discussion during the rights issue has been, of course, the downside risk relative to what's gonna happen in the US. We have been sort of elaborating a lot about that because of the stop work order and the sort of the risk of getting more stop work orders. I do think that, along with the rights issue, we have explained the reason why we thought the DKK 60 billion was the right number. We have communicated that we expect this Hornsea Three transaction to be signed and closed during the year.

Speaker #5: So in starting to say that , of course , a lot of the discussion during the rights issue has been , of course , the downside risk relative to what's going to happen in the US .

Speaker #5: We have been sort of elaborating a lot about that because of the stop work order and the sort of the risk of getting more stop work orders .

Speaker #5: I do think that along with the rights issue , we have explained the reason why we thought the 60 billion was the right number .

Speaker #5: We have communicated that we expect this Hornsea Three transaction to be signed and closed during the year , so that has been a part of our base case all the time .

Trond Westlie: That has been a part of our base case all the time. The downside risk is, of course, that things may happen of uncertainties in the US that we cannot sort of put in a probability or an estimate on. As we have said all along, we have committed so much money into the projects of Sunrise and Revolution, that closing it down is not really a good case for us because our commitment cost is almost as high as the total cost of the project. That is why we have looked at these structures and also the capital raise in this context. It is hard now to see situation that we will come into That we will be downgraded into a non-investment grade.

Speaker #5: The downside risk is , of course , that things may happen of uncertainties in the US that we cannot sort of put in .

Speaker #5: Probability or an estimate on . But as we have said all along , we have committed so much money into the projects of sunrise and revolution that closing it down is not really a good case for us because our commitment cost is almost as high as the total cost of the project .

Speaker #5: That is why we have looked at these structures and also the capital raise in this context . It is hard now to see situation that we will come into a situation that we will be downgraded into a non-investment grade .

Speaker #5: So the scenarios you need to develop to actually get us there is now , of course , much more difficult when we have the Hornsea Three in place .

Trond Westlie: The scenarios you need to develop to actually get us there is now, of course, much more difficult when we have the Hornsea Three in place. Over to you, Rasmus.

Speaker #5: So over to you , Rasmus .

Speaker #2: Thank you very much . Thank you Alberto . Yeah . So I think probably two , two , two parts to the answer on the repositioning of us on the other side of 28 .

Rasmus Errboe: Thank you very much. Thank you, Alberto. Yeah. I think probably two parts to the answer on the repositioning of Ørsted on the other side of 28. First, part is, Alberto, that it is for us to deliver on our plan. That is really our main focus. We have a plan centered around four priorities. To have a robust capital structure, to construct our 8.1 GW of offshore wind projects in the best possible way, to stay focused and disciplined on capital allocation, always prioritizing value over volume, and then also improve our competitiveness. If you sort of look at our progress across the board across these four priorities in Q3, you can see that that is really where we focus.

Speaker #2: First part is Alberto . That it is for us to deliver on our plan . That is really our our main focus . We have a plan with centered around four priorities to have a robust capital structure to construct our 8.1GW of offshore wind projects in the best possible way to stay focused and disciplined on capital allocation .

Speaker #2: Always prioritizing value over volume . And then also improve our competitiveness . And if you sort of look at our progress across the board on across these four priorities in Q3 you , you can see that that is really where , where we focus .

Speaker #2: So the best way , in my view , to position us for 28 and onwards is by delivering on our plan , we will be in a very , very different position and we will be able to meet the market from a position of strength at that point in time .

Rasmus Errboe: The best way, in my view, to position us.

Trond Westlie: For 2028 and onwards is by delivering on our plan, we will be in a very, very different position and we will be able to meet the market from a position of strength at that point in time when we deliver on our plan. Second part is sort of how do we then think about 2028 and onwards. You talked about different kinds of sort of growth measures and what is out there. We are remain very bullish about the prospects for offshore wind in Europe in particular. We see the rebasing happening in the market. The growth pockets for offshore wind in Europe, in my view, span across 3, if you will. One is, of course, the centralized tenders.

Speaker #2: When we deliver on our plan . Second part is sort of how do we then think about 2028 and onwards ? You talked about different kinds of sort of growth measures and what is out there .

Speaker #2: We are remain very bullish about the prospects for for offshore wind in Europe in particular . We see the rebasing happening in the market and the growth pockets for offshore wind in Europe .

Speaker #2: In my view , span across three , if you will . One is of course the centralized tenders . There are 26 is probably going to be a little bit on the on the low side in terms of numbers of tenders that are being put out there .

Trond Westlie: 26 is probably gonna be a little bit on the low side, in terms of numbers of tenders that are being put out there. From 27 and onwards, it would take a bit of a step change. That is one pocket that we could pursue. The other one is, of course, to mature our proprietary pipeline. The third pocket is more, I would not call it inorganic, but a more, you could say, project by project collaboration ships or M&A. Those are and basically have always been the pockets that we are looking for, when we, when we think about offshore wind growth. We will be patient and we will prioritize value over volume.

Speaker #2: But then from 27 and onwards it would take a bit of a step change . So that is one pocket that we could pursue .

Speaker #2: The other one is of course to mature our proprietary pipeline . Then the third bucket is more , I would not call it inorganic , but a more you can say project by project collaboration or M&A .

Speaker #2: Those are and basically have always been the buckets that we are looking for when we when we think about offshore wind growth . But we will be patient and we will prioritize value over volume .

Speaker #2: .

Speaker #11: You've been so interesting that can I ask you a follow up ? Appreciate if you say no .

Alberto Gandolfi: You've been so interesting, but can I ask you a follow-up? Appreciate if you say no.

Speaker #2: Go ahead .

Trond Westlie: Go ahead.

Speaker #11: Thank you so much . I'm very this is all very clear . I'm just very intrigued by the comment you made about , you know , refocusing on Europe and potentially openness project by project M&A .

Alberto Gandolfi: Thank you so much. I'm very. This is all very clear. I'm just very intrigued by the comment you made about, you know, refocusing on Europe and potentially openness project by project M&A. Would this also include potentially bigger platforms? I think it's no secret that probably lots of people on this call are thinking about the offshore portfolio of Equinor that would take out a competitor. You know, at that point, your balance sheet is very strong. Would this be an option worth pursuing, you think?

Speaker #11: Would this also include potentially bigger platforms ? I think it's no secret that probably lots of people on this call are thinking about the offshore portfolio of Equinor , that would take out the competitor .

Speaker #11: And , you know , at that point , your balance sheet is very strong . Would this be an option worth pursuing ? I think .

Speaker #2: That is not in our plans.

Trond Westlie: That is not in our plans.

Speaker #11: Thank you so much .

Alberto Gandolfi: Thank you so much.

Speaker #1: The next question comes from the line of Lars Heindorf from Nordica . Please go ahead .

Operator: The next question comes from the line of Lars Hindorf from Nordea. Please go ahead.

Speaker #12: Yes . Afternoon . Thank you for taking my questions . The first one is regarding the correlation between EBITDA and operating cash flow .

Lars Hindorf: Yes, afternoon. Thank you for taking my questions. The first one is regarding the correlation between EBITDA and operating cash flow. You had a few questions about this already, maybe it's sort of a follow-up. You've been guiding for 2025 to 2027, operating cash flow of DKK 50 billion. We take the midpoint of the EBITDA guidance this year and then, the minimum guidance that you've been providing for 2026 and 2027, that will add up to DKK 86 billion of EBITDA in the same period and a conversion ratio which is less than 60%. How should we think about the correlation of between EBITDA and operating cash flow going forwards, first foremost in the other nine to 2027?

Speaker #12: You had had a few questions on this already , so maybe sort of a follow up , but you've been guiding for 25 to 27 .

Speaker #12: Are operating cash flow of 50 billion . If we take the midpoint of EBITDA guidance this year and then the minimum guidance that you've been providing for 26 and 27 , that will add up to 86 billion of EBITDA in the same period .

Speaker #12: And a conversion ratio , which is less than 60% . So how should we think about the correlation of between and operating cash flow going forward ?

Speaker #12: First , foremost , in the harbor , 1927 , and I think given the development in handsfree and the first three years with a 5050 split , that should be fine .

Lars Hindorf: I think given the development in 1 to 3 and the first 3 years with a 50/50 split, that should be fine. Beyond that's maybe too far out. Just to get a sort of sense for what you expect in terms of operating cash flow for the coming years. Yeah. That's the first part. Then the second part, just the housekeeping, which is, Trance, you mentioned the Changhua transaction. How much exactly would that impact the net interest paying debt for this year? Thank you.

Speaker #12: But beyond that , that's maybe too far out . But just to get a sort of sense for what what you expect in terms of operating cash flow for the coming years .

Speaker #12: Yeah , that's that's the first part . And then the second part , just the housekeeping , which is you mentioned the shanghua transaction .

Speaker #12: How much exactly would that impact the interest bank debt for this year ? Thank you .

Speaker #5: Well , well , on the operational cash flow relative to the FDA , there are three sort of buckets of elements that comes into the difference .

Trond Westlie: Well, well, on the operational cash flow relative to the EBITDA, there are three sort of buckets or elements that comes into the difference. It's the taxes paid, it's the reversal of non-cash tax equity in EBITDA, and it's basically a working capital of those changes. That is the major bucket. That's the three buckets. There is, of course, ups and down relative to working capital changes that goes in there. Those three elements, taxes paid, reversal of non-cash tax equity in EBITDA, and working capital of those changes, is the three elements that really drives the bridge between the 50 and the EBITDA elements. That's, that's those elements.

Speaker #5: It's the taxes paid . It's the reversal of non-cash tax equity in EBITDA . And it's basically working capital of those changes . That is the major bucket .

Speaker #5: That's the three buckets . And then there is of course ups and downs relative to working capital changes . That goes in there .

Speaker #5: But those three elements taxes paid , reversal of non-cash tax equity in EBITDA and working capital of the changes is the three elements that really drives the bridge between the 50 .

Speaker #5: The the EBITDA elements . So that's that's those elements . And when it comes to the to the Zhanghua to before and the transaction , we still have the ambition to sign the transaction during the year .

Trond Westlie: When it comes to the Changhua tubing four and the transaction, we still have the ambition to sign the transaction during the year. Since we're not able to close the transaction during the year, there will be no transaction as such. There will be not debt reduction as a result of that. The statements that we have made earlier when it comes to the DKK 35 billion of the proceeds guideline that we have for 2025 and 2026, we have the DKK 7 billion that we did before half year. We now have the DKK 10 billion from Hornsea three, the two outstanding elements short of DKK 20 billion left. That's basically evenly divided between the Changhua and the EU onshore transaction.

Speaker #5: But since we're not able to close the transaction during the year that that there will be no transaction as such . So there will be not debt reduction as a result of that .

Speaker #5: So the statements that we have made earlier , when it comes to the 35 billion of the proceeds guideline that we have for 25 and 26 , we have the 7 billion that we did before , half year .

Speaker #5: We now have the $10 billion from Hornsea Three, and then the two outstanding elements are around $20 billion short of $20 billion left.

Speaker #5: And that's basically evenly divided between the Changhua and the euro . EU onshore transaction . So and as I said Changhua will not be close during the year .

Trond Westlie: As I said, Changhua will not be closed during the year, so no effect.

Speaker #5: So no effect . .

Speaker #12: Okay . And just to follow up on the first part , which is the conversion between to cash flow , is that fair to assume that when you get to 28 , which will be the first year at least as we look right now without any offshore CapEx , that you will have to still the same relationship , which is around slightly below 60% cash conversion from EBITDA to operating cash flow .

Lars Hindorf: Okay. Just to follow up on the first part, which is the conversion between EBITDA to operating cash flow. Is that fair to assume that when you get to 2028, which will be the first year, at least as we look right now without any offshore CapEx, that you have to still the same relationship, which is around slightly below 60% cash conversion from EBITDA to operating cash flow?

Trond Westlie: I need to get back to that on that because the 11 to 12 coming out of the 6 projects is not gonna be evenly divided as a result of how much of tax equity that comes into that, gross up. Not quite sure I can guide you on that right now.

Speaker #5: I need to get back to that . On that , because the 11 to 12 coming out of the six projects is not going to be evenly divided as a result of how much of tax equity that comes into that gross up .

Speaker #5: So, I'm not quite sure I can guide you on that right now.

Speaker #12: Okay . All right . Thank you .

Lars Hindorf: All right. Thank you.

Speaker #1: We now have a question from the line of Deepa Venkateswaran from Bernstein . Please go ahead .

Operator: We now have a question from the line of Deepa Venkateswaran from Bernstein. Please go ahead.

Speaker #13: Thank you . I wanted to quiz you a bit on what the Equinor's CEO has been saying about offshore wind . And Orsted , where he's been talking about new business models , the need for consolidation and industrial cooperation with Orsted .

Deepa Venkateswaran: Thank you. I wanted to quiz you a bit on what the Equinor CEO has been saying about offshore wind and Ørsted, where he's been talking about new business models, the need for consolidation and industrial cooperation with Ørsted. What are your thoughts on any cooperation with Equinor and what form and over what timeline? That's the question. If you can't answer that, then I have another question which I'd like to ask.

Speaker #13: What are your thoughts on any cooperation with Equinor and what form and over what timeline ? So that's the question . If you can't answer that , then I have another question which I'd like to ask .

Speaker #2: Give it a go deeper . Thank you very much . No . So I think first of all , we are of course very pleased with with the support that we continue to receive from , from Equinor as the , as the second largest shareholder , we have no doubt about it .

Rasmus Errboe: I'll give it a go, Deepa. Thank you very much. Now, I think first of all, we are of course very pleased with the support that we continue to receive from Equinor as the second largest shareholder. We have no doubt about it. Of course, I have also noted the comments that you are alluding to. Our focus right now, my focus right now, is to deliver on our plan. Is to deliver on our strategy quarter by quarter, centered around the four priorities that I mentioned before.

Speaker #2: And of course , I have I have also I have also noted , noted the comments that you are alluding to our focus right now .

Speaker #2: My focus right now is to deliver on our plan, which is to deliver on our strategy quarter by quarter, around the four priorities that I mentioned before.

Rasmus Errboe: I, of course, as any responsible management team, if you look further out in time, of course, you will look at all options that would improve the value for your shareholders, no doubt about it. I am confident that we in Ørsted have a very well-suited business model for offshore wind.

Speaker #2: I of course , as any any responsible management team , if you look further out in time , of course you will look at all .

Speaker #2: Options that would improve the value for for your for your shareholders . No doubt about it . I am I am . Confident that that we in still have a very well suited business model for offshore wind .

Speaker #13: Okay . Thank you .

Deepa Venkateswaran: Okay. Thank you.

Speaker #1: The next question comes from the line of Jenny Ping from Citi . Please go ahead .

Operator: The next question comes from the line of Jenny Ping from Citi. Please go ahead.

Speaker #14: Thanks very much . So two questions I have are somewhat linked . Firstly , just on the negative construction EBITDA that you printed in three Q that you say is linked with the Greater Changhua four project , and given some of the cost overruns that you highlighted , are we expecting this to be this magnitude effectively until the close of the project ?

Jenny Ping: Thanks very much. The two questions I have are somewhat linked. Firstly, just on the negative construction EBITDA that you printed in Q3 that you say is linked with the Greater Changhua 4 project, and given some of the cost overruns that you highlighted, are we expecting this to be this magnitude effectively until the close of the project at COD in 2026, so DKK 300 to 400 million negative each quarter? Just linked to that, I guess, going back to the Apollo deal, Rasmus, you know, clearly this is a fully EPC wrapped project, which you will take on any overspend and any delays risk.

Speaker #14: Cod in 2026 ? So three 400 million negative each quarter . And then just linked to that , I guess going back to the Apollo deal , Rasmus , you know , clearly this is a fully EPC wrapped project , which you will take on any overspend and any delays risk .

Speaker #14: So what sort of comfort can you give to the investors that this project has been operationally de-risked as the go into the full construction phase to minimize any of the delays and overruns , which ultimately will be borne by Orsted .

Jenny Ping: What sort of comfort can you give to the investors that this project has been operationally derisked, as we go into the full construction phase, to minimize any of the delays and overruns which ultimately will be borne by Ørsted? Thanks.

Speaker #14: Thanks .

Speaker #5: Just taking the negative of the the construction agreement provision that we made in the third quarter , that is , of course , the full amount of loss that we expect to have on the construction agreement on Changma four .

Trond Westlie: Just taking the negative or the construction agreement provision that we made in Q3. That is, of course, the full amount of loss that we expect to have on the construction agreement on Changhua 4. It's not a repetitive element. It's an estimate of the full full loss on the construction agreement.

Speaker #5: So it's not a repetitive element . It's a estimate of the full , full loss on the construction agreement .

Speaker #2: Arginine . And as for as for Hornsea Three , you are right that the way we have we have done the CA is is you can say our normal model where we where we where we wrap sort of parts of the construction risk the same way as it is also our normal model on the , on the OMA part where we do own M for , for for our partner , we are progressing very much according to plan on Hornsea .

Rasmus Errboe: Hi, Jenny. As for Hornsea Three, you are right that the way we have done the CA is you can say our normal model, where we wrap sort of parts of the construction risk the same way as it is also our normal model on the OMA part, where we do O&M for our partner. We are progressing very much according to plan on Hornsea Three. It's of course a very big project, 197 positions. It is in our core market, and it is in a zone that we are comfortable working with.

Speaker #2: Hornsea three . It's of course a very big project , 197 positions , but it is in , in our core market and it is in a , in a zone , in a zone that we are comfortable working with .

Speaker #2: Some of the things we have been focused on in the beginning from a from a construction risk perspective , if you will , are going quite well .

Rasmus Errboe: Some of the things we have been focused on in the beginning from a construction risk perspective, if you will, are going quite well. The onshore converter stations and the cable landfall is progressing. That is a key focus point for us. Also making sure that we get, that we can deliver, also National Grid can deliver on time. We have no reason to believe not to. When we get to that point in 2027. Monopiles has been a key focus for us. We have now sufficient robustness on the supply chain for that project on the monopile side.

Speaker #2: The onshore converter stations and the cable landfall is progressing . That is a key focus point for us . Also , making sure that that we get that , that we can deliver also National Grid can deliver on time .

Speaker #2: We have no reason to believe not to when when we get get to that point in 27 , Monopiles has been a key focus for us .

Speaker #2: We have now sufficient robustness on the supply chain for that project , on the Monopile side , we have sort of a roughly a handful of monopile suppliers on on the project .

Rasmus Errboe: We have sort of a roughly a handful of monopile suppliers on the project: EEW, Hyundai Steel Wind, to name a few. We have a great deal of flexibility in terms of making sure that if one is not exactly on time, then someone else can deliver. We are starting to see monopiles being produced with a couple of them. That is very, very much on track. Half of the export cables have been produced. The offshore monopile installation will start in Q2. Also, as I said before, the two offshore converter stations are progressing according to plan, one already in Norway from Thailand, the other one on its way.

Speaker #2: CW Isaiah Steel Wind , to name a few . And and we have a great deal of flexibility in terms of making sure that if if one is not exactly on time , then someone else can deliver .

Speaker #2: And we are starting to see Monopiles being produced with , with , with a couple of them . So that is very , very much on track .

Speaker #2: Half of the export cables have been produced . The , the , the offshore Monopile installation will start in Q2 and also , as I said before , the two offshore converter stations are progressing according to plan one already in Norway from Thailand , the other one on its way .

Speaker #2: One thing that we and I have been focusing on , and that's my last point from from the very beginning , has also very much been on installation vessels .

Rasmus Errboe: One thing that we and I have been focusing on, and that's my last point, Jeanette, from the very beginning, has also very much been on installation vessels. We have 3 installation vessels that will do the work on Hornsea 3. One of them is now done here in September, so during Q3. That is very good. The other one is working on other projects. One of the 2 turbine installation vessels, the Wind Peak is now working for Sofia and on the East Anglia 3. That is all fine. The last one is being produced, and we expect for it to be done by the end of the year.

Speaker #2: We have three installation vessels that will do the work on on Hornsea Three and one of them is is now done here in September .

Speaker #2: So during Q3 that is very good . The other one is working on other projects . So so one of the two turbine installation vessels , the wind peak , is , is is now working for Sophia and , and on the East Anglia three .

Speaker #2: So , so that is all fine . And then the last one is being produced . And we expect for it to be done by the end of the year .

Speaker #2: So I would say across the board construction and thereby construction risk is progressing according to plan .

Rasmus Errboe: I would say across the board, construction and thereby construction risk is progressing according to plan.

Speaker #14: Thank you very much .

Jenny Ping: Thank you very much.

Speaker #1: We now have a question from the line of Jacob Pedersen from Citibank . Please go ahead .

Operator: We now have a question from the line of Jacob Pedersen from Sydbank. Please go ahead.

Speaker #15: Yeah . Hi . Hi , guys . Just a question from me regarding Baltika three . You still have it as a part of your your pipeline in offshore in your presentation .

Jacob Pedersen: Yeah. Hi, guys. Just a question from me regarding Baltica 3. You still have it as a part of your pipeline in offshore in your presentation. What is the status on this project? Will it play any role in bridging the standstill in new installations after 2027? Or will it be more attractive for you to go into other auctions, Søren?

Speaker #15: What are the what is the status on this project and will it play any role in bridging the standstill and new installations after 2027 , or will it be more attractive for you to to go into to other auctions ?

Speaker #15: Do you think ?

Speaker #2: Thank you , thank you Jakob Baltika three is a project that we jointly own . As you know , together with our partner PGE .

Rasmus Errboe: Thank you. Thank you, Jacob. Baltica 3 is a project that we jointly own, as you know, together with our partner, PGE. We continue to be very, very pleased with that partnership, and we are also moving forward with PGE on Baltica 2. As you know, we put Baltica 3 under reconfiguration a few years ago now. The reason being that we didn't see sufficient value as the project stands in our portfolio to move it forward. That is still the case. The project is under a reconfiguration, and we will only move it forward if we see a significant improvement in the value.

Speaker #2: We continue to be very , very pleased with that partnership . And we are also moving forward with PGE and political to , as you know , we we we put Baltic three under reconfiguration a few years ago .

Speaker #2: Now . And the reason being that we didn't see sufficient value as the project stands in , in , in our portfolio to , to move it forward .

Speaker #2: That is , that is , that is still the case . The project is under reconfiguration and we will only move it forward if we see a , a significant improvement in , in the value .

Speaker #2: So it is one of the options that we have in our portfolio . But as I said before , it would also have to have to stack up against the other opportunities .

Rasmus Errboe: It is one of the options that we have in our portfolio. As I said before, it would also have to stack up against the other opportunities. We are very strict on value over volume, and also on capital discipline and allocation. That is what I can say about Baltica 3 right now.

Speaker #2: We are very strict on value over volume and also on capital discipline and allocation . So , so that that is what I can say about Baltika three right now .

Speaker #15: Okay . If I may , a second one , just housekeeping , the rights issue cost , will we see that in financing costs during Q4 or is it already in the Q3 numbers .

Jacob Pedersen: Okay. If I may, a second one, just housekeeping. The rights issue cost, will we see that in financing cost during Q4, or is it already in the Q3 numbers?

Speaker #5: It will come in the Q4 numbers , but but having said that , there was a good estimate in the prospectus . So I think you can if you want to have an estimate , you can use that .

Rasmus Errboe: It will come in the Q4 numbers. Having said that, there was a good estimate in the prospectus. I think you can, if you want to have an estimate, you can use that.

Speaker #5: Yeah .

Speaker #15: Yeah .

Jacob Pedersen: Yeah. Yeah. Thanks.

Speaker #7: Thanks .

Speaker #1: The next question comes from the line Ollie Jeffrey from Deutsche Bank . Please go ahead .

Operator: The next question comes from the line of Olly Jeffery from Deutsche Bank. Please go ahead.

Speaker #15: Hi . Thanks .

Speaker #16: Good afternoon . My first question is that my understanding is that Judge Lambert , in some revolution wind . So John Lambert , who put in place the preliminary injunction is likely to be writing a detailed opinion , which we haven't received yet .

Olly Jeffery: Hi. Thanks. Good afternoon. My first question is that my understanding is that Judge Lamberth from Revolution Wind, so Judge Lamberth, who put in place the preliminary injunction, is likely to be writing a detailed opinion, which we haven't received yet. That if the Trump administration were to appeal the injunction, that would most likely happen after that detailed opinion has been written. Would you agree with that broad assessment? The second question is just on the Section 232 investigation into wind components. Has there been any development on that? Are you able at all to say if it were to lead to further tariffs, would that be of any material consequence in terms of impairments, or is that not such a risk to you?

Speaker #16: And that is the Trump administration were to

Speaker #16: most likely happen after that detailed opinion has been written . Would you agree with that broad assessment ? And then the second question is just on the section 232 investigation , into of wind components .

Speaker #16: There's been any development on that . And are you able at all to say if were to lead to further tariffs , would that be of any material consequence in terms of impairments , or is that not such a risk ?

Speaker #16: Do you .

Speaker #2: Thank you . Olli , I can take the appeal and then I will leave the tariff question to to to front and I will be quite brief .

Rasmus Errboe: Thank you, Olly. I can take the appeal. I will leave the tariff question to Trond. I will be quite brief, Olly. I don't want to speculate in potential legal outcomes and whether or not something will be appealed, and if so, when. We rely on the injunction that we received on the 22 September by Royce Lamberth. We were immediately back to work, and that is very much our focus. As I said before, we are pursuing two avenues, still, the legal track and also the conversation track, and our aim is to get a complete solution for Revolution Wind.

Speaker #2: Olli , I don't want to . I don't want to speculate in potential legal outcomes and whether or not something will be appealed .

Speaker #2: And if so , when we we rely on the injunction that we received on the 22nd of September by Judge Lambert and we were immediately back to work , and that is very much our focus .

Speaker #2: But as I said before , we are pursuing two avenues . Still , the legal track and also the conversation track , and our aim is to get a complete solution for Revolution Wind .

Speaker #5: And just to be to be clear , firm or have a clear view of where the tariff goes in the US , it's quite difficult .

Rasmus Errboe: Just to be clear, firm, or have a clear view of where the tariff goes in the US, it's quite difficult.

Speaker #5: So but what we have taken into consideration is , of course , the June 4th announcement , the 19th announcement and the 24th 21st announcement .

Trond Westlie: What we have taken into consideration is of course the 4 June announcement, the 19th announcement, and the 21st announcement. That means that we have looked at the inquiry of the specific imports for wind turbines and associated parts. We have included the more than 400 items that they have included on the list. As such, we have also considered the 50% level. That is really the elements that we can do as best estimate as of now. That is what we have included in our best estimate. That gets us to the DKK 2.5 billion of impairment effect in Q3.

Speaker #5: That means that we have looked at the inquiry of the specific imports for wind turbines and associated parts . We have included the more than 400 items that they have included on the list , as such , we have also considered the 50% level , and that is really the elements that we can do as best estimate .

Speaker #5: As of now . And that is what we have included in our best estimate that gets us to the 2.5 billion of impairment effect in the third quarter .

Speaker #16: Thank you .

Robert Pulleyn: Thank you.

Olly Jeffery: Thank you.

Speaker #1: We now have a question from the line of Roland Hartvigsen from Clarksons Securities . Please go ahead .

Operator: We now have a question from the line of Roald Hartvigsen from Clarksons Securities. Please go ahead.

Speaker #17: Good afternoon , gentlemen , and thanks for taking my question on gross investments . You keep your 50 to 54 billion guidance and and given that you have already spent about 40 billion so far this year , the low end of your guidance would suggest only an additional 10 billion for the last quarter , which seems like quite a material step down compared to the 15 billion this quarter , especially given the fact that the reported CapEx figures historically have been quite high in the end of the year quarter , and that the full haunted three project will still be on your books , I guess at least part of the quarter or so .

Robert Pulleyn: Good afternoon, gentlemen, thanks for taking my question. On gross investments, you keep your DKK 50 to 54 billion guidance. Has changed? Given that you've already spent about DKK 40 billion so far this year, the low end of your guidance was just only an additional DKK 10 billion for the last quarter. Which is like quite a material step down compared to the DKK 15 billion this quarter. Especially given the fact that reported CapEx historically have been quite high in the end of the year quarter, and that the full on the three projects will still be under booked, I guess at least part of the quarter or so.

Roald Hartvigsen: Good afternoon, gentlemen, thanks for taking my question. On gross investments, you keep your DKK 50 to 54 billion guidance. Has changed? Given that you've already spent about DKK 40 billion so far this year, the low end of your guidance was just only an additional DKK 10 billion for the last quarter. Which is like quite a material step down compared to the DKK 15 billion this quarter. Especially given the fact that reported CapEx historically have been quite high in the end of the year quarter, and that the full on the three projects will still be under booked, I guess at least part of the quarter or so.

Speaker #17: So can you help us reconcile the expected drop in the investment level from the third quarter? And give some color on what assumptions are embedded in, especially the lower end of the gross investment guidance range here.

Robert Pulleyn: Can you help us reconcile the expected drop in the investment level from the third quarter and give some color on what assumptions are embedded in especially the lower end of the gross investment guidance range here? Thanks.

Roald Hartvigsen: Can you help us reconcile the expected drop in the investment level from the third quarter and give some color on what assumptions are embedded in especially the lower end of the gross investment guidance range here? Thanks.

Speaker #17: Thanks .

Speaker #5: I do think that you have to take the full guidance into perspective . Basically 50 to 54 , and that if you take the upper number , it's actually going to be around the same number in gross investments in fourth quarter as in third quarter .

Trond Westlie: I do think that you have to take the full guidance into perspective, basically DKK 50 to 54. That if you take the upper number, it's actually gonna be around the same number in gross investments in Q4 as in Q3, if you take that as a sort of a possibility. Having said that, I think the important element to this is not necessarily the timing, whether the payment is done the 20 December or the 10 January. The important thing is that our investment level for all the 3 years is around DKK 145 billion.

Speaker #5: If you take that as a sort of a possibility . Having said that , I think the the important element to this is not necessarily the timing , whether the payment is done , the 20th of December or the 10th of January , the important thing is that our investment level , for all the three years is around 145 billion , as we have said earlier , we expect that to be 50 to 50 for this year .

Trond Westlie: As we have said earlier, we expect that to be 50 to 54 this year. That means that it's gonna be sort of in the 50 range for the two consecutive years, so 2026 and 2027. I think it's important not to sort of be razor sharp on 31 December. Our best guess as of now and the sensitivity we have relative to timing of payments as the year end is between 50 and 54.

Speaker #5: And that means that it's going to be sort of in the 50 range for the the the two consecutive years of 26 and 27 .

Speaker #5: So I think it's important not to sort of be razor sharp on 31st of December . But our best guess as of now and the sensitivity we have relative to timing of payments as the year end is between 50 and 54 .

Speaker #17: Thank you . That's it from my side .

Robert Pulleyn: Thank you. That's it from my side.

Roald Hartvigsen: Thank you. That's it from my side.

Speaker #1: The next question comes from the line of Rob Paulsen from Morgan Stanley . Please go ahead .

Operator: The next question comes from the line of Rob Polain from Morgan Stanley. Please go ahead.

Speaker #18: Thank you . Lots of questions already answered . So if I may just ask something a bit nitty gritty on slide 23 , I noticed some of these numbers have changed since two Q so when we look at the 10% ITC bonus sensitivity impact , sunrise , and Revolution now add up to 6 billion kroner .

Robert Pulleyn: Thank you. Lots of questions already answered. If I may just ask something a bit nitty-gritty. On slide 23, I noticed some of these numbers have changed since Q2. When we look at the 10% ITC bonus sensitivity impact, Sunrise and Revolution now add up to DKK 6 billion. Previously I think that was DKK 4.6 billion. The sensitivity to a 50 basis point move in WACC is now DKK 2.1 billion. Previously it was less. Just wondering what was going on there? If I can just ask a clarification from earlier, 'cause the audio was a bit crackly. Did you confirm you hope to announce the deal on Changhua 2 in 2025?

Rob Pulleyn: Thank you. Lots of questions already answered. If I may just ask something a bit nitty-gritty. On slide 23, I noticed some of these numbers have changed since Q2. When we look at the 10% ITC bonus sensitivity impact, Sunrise and Revolution now add up to DKK 6 billion. Previously I think that was DKK 4.6 billion. The sensitivity to a 50 basis point move in WACC is now DKK 2.1 billion. Previously it was less. Just wondering what was going on there? If I can just ask a clarification from earlier, 'cause the audio was a bit crackly. Did you confirm you hope to announce the deal on Changhua 2 in 2025?

Speaker #18: And previously I think that was 4.6 . And the sensitivity to a 50 basis point move in WACC is now 2.1 billion . And previously it was less .

Speaker #18: Just wondering what was going what was going on there . And if I can just ask a clarification from earlier because the the audio was a bit crackly , did you confirm you hope to to announce the deal on Changhua 2 in 2025 ?

Speaker #18: I know you answered that you expect to close it in 2026 , but is the disposal still going to happen this year ? Thank you very much .

Robert Pulleyn: I know you answered that you expect to close it in 2026, but is the disposal still gonna happen this year? Thank you very much.

Rob Pulleyn: I know you answered that you expect to close it in 2026, but is the disposal still gonna happen this year? Thank you very much.

Speaker #5: When it comes to the the slide 23 , the the the reason for changes is of course , changes in some of the CapEx levels .

Trond Westlie: When it comes to the slide 23, the reason for changes is of course changes in some of the CapEx levels. The elements, I don't have the sort of the gross numbers in top of my head, so you have to contact IR to actually get the more detailed level in that. When it comes to the Changhua transaction, yes, we still have the ambition to sign the deal during this year, and then close it when we have COD in Q3 next year.

Speaker #5: So the elements I don't have the sort of the gross numbers in top of my head . So you have to contact IR to actually get the the more detailed level in that when it comes to the transaction .

Speaker #5: Yes , we still have the ambition to sign the deal during year and then close it when we have Cod in the third quarter next year .

Speaker #18: Thank you very much . Very clear .

Robert Pulleyn: Thank you very much. Very clear.

Rob Pulleyn: Thank you very much. Very clear.

Speaker #1: We now have a question from the line of David Potts from Wolfe . Please go ahead . Mr. Potts , your line is now open .

Operator: We now have a question from the line of David Paz from Wolfe. Please go ahead. Mr. Paz, your line is now open. You may go ahead with your question.

Speaker #1: You may go ahead with your question .

Speaker #19: I'm sorry about that . I hopefully you can hear me now . Thank you for the time . Just wanted to follow up on , on Revolution Wind .

David Paz: I'm sorry about that. Hopefully you can hear me now. Thank you for the time. Just wanted to follow up on Revolution Wind. Just two quick questions. A, it's the DKK 5 billion. Has that been updated since August in terms of the remaining investment? I think that was your share. Then, B, what, of those three items you've listed, onshore substation, the turbine, remaining turbines, and the array cables, which are, would you say they're like first and last? In other words, like, what is the critical path, I guess? If you can just give us some color, particularly given the comments on the onshore substation being substantially complete, just what gets you to second half 2026 COD. Thank you.

Speaker #19: Just two quick questions . A is the 5 billion kroner has that been updated since August in terms of the remaining investment ? I think that was your share .

Speaker #19: And then B what of those three items you've listed onshore substation , the turbine remaining turbines and the array cables , which are the would you say are the first and last ?

Speaker #19: In other words , like what ? What is the critical path ? I guess if you can just give us some color , particularly given the comments on the onshore substation being substantially complete , just what gets you to a second half ?

Speaker #19: 2026 Todd thank you .

Speaker #5: When it comes to the the the CapEx on revolution , yes , our total CapEx , our 50% share of the CapEx is 20 .

Trond Westlie: When it comes to the CapEx on Revolution, yes, our total CapEx, our 50% share of the CapEx is $20. As last quarter, we had spent about $15 billion on that. The remaining $5 for us, $10 in total for Revolution, has sort of been paid during the time. Basically, but I think it's more important that we have come so far on the Revolution that the commitment we have on the whole value is there. Whether we have paid it or not doesn't really matter relative to the timing of it. It's more the timing of things.

Speaker #5: And as I last quarter , we we had spent about 15 billion of that . So the remaining five for us , ten in total for revolution has sort of been paid during the time .

Speaker #5: And basically . But I think it's more important that we have come so far on the revolution that the commitment we have on the whole value is there .

Speaker #5: So whether we have paid it or not doesn't really matter . Relative to the timing of things . It's more the timing of things .

Speaker #2: And with respect to the critical path for Revolution Wind, it is still the onshore substation that is on the critical path.

Rasmus Errboe: With respect to the critical path for Revolution Wind, it is still the onshore substation that is on the critical path. It is moving forward well, as I said, on both the turbine installations with 52 and on array cables with 41 out of the 65. So, as I said, we expect the energization of the onshore substation early next year. The reason that is still on the critical path is that following the energization of the onshore substation, you then basically go area by area in the wind park, starting with the export cables, then onto the offshore substations and then the turbines in terms of the e-electrification and the hot commissioning of the turbines.

Speaker #2: It is moving forward . Well , as I said on on both the turbine installations with 52 and on array cables with , with 41 out of the 65 .

Speaker #2: So , so and we as I said , we we expect energization of the onshore substation early next year . But the reason that is still on the critical path is that following the initiation of onshore substation , you then basically go area by area in the wind park , starting with the export cables , then on to the offshore substations and then and then the turbines .

Speaker #2: In terms of the electrification and the commissioning of the turbines . And that takes that , that brings us into our expectations for Cod .

Rasmus Errboe: And that takes, that brings us into our expectations for COD. Still on the critical path, the onshore substation.

Speaker #2: So still , on the critical path , the onshore substation .

Speaker #19: Okay . Thank you . Thank you for the color .

David Paz: Okay, thank you. Thank you for the color.

Speaker #1: We have a follow up question from the line of Mark Freshney from UBS . Please go ahead .

Operator: We have a follow-up question from the line of Mark Freshney from UBS. Please go ahead.

Speaker #10: Hello . Thank you . Just regarding security of some of the subsea cables , you know , we know that there's a lot of work being done at the industry .

Mark Freshney: Hello, thank you. Just regarding, you know, security of some of the subsea cables. You know, we know that there's a lot of work being done at the industry and government and NATO level on protection of those cables. From your perspective, have any of your subsea cables been, you know, knowingly sabotaged? When you think about that at board level as a risk to the business, how are you tackling that from your own internal perspective?

Speaker #10: And government and NATO level on protection of those cables . But from your perspective , have any of your subsea cables been knowingly sabotaged ?

Speaker #10: And when you think about that at board level , as a risk to the business , how are you ? You tackling that from from your own internal perspective ?

Speaker #2: Thank you . Thank you . Mark . Mark , as I'm sure you can appreciate , I will I will not be super granular on on this on this question .

Rasmus Errboe: Thank you. Thank you, Mark. Mark, as I'm sure you can appreciate, I will not be super granular on this question. I'm not gonna comment on sort of impacts on individual cables and what have you. What I can say is that you can say security and working with governments and also you mentioned NATO before is something that has been part of the way we do development in Europe for a very long time. The governments are asking for conversations and solutions for defense coexistence, and we see very good cooperation between the relevant authorities in the markets that we are in, and also the sector, including us, to develop successful mitigations from a coexistence perspective.

Speaker #2: So I'm not going to comment on sort of impacts on individual cables and what have you , what I can say is that you can say security and working with the governments and and also , you mentioned NATO before , is is something that has been part of the way we do development in Europe for a very long time .

Speaker #2: Governments are asking for conversations and solutions for . For , for defensive coexistence . And we see very good cooperation between the relevant authorities in the markets that we are in .

Speaker #2: And also the sector , including us , to develop a successful mitigations from a coexistence perspective . That is , as far as I can take it in terms of defense .

Rasmus Errboe: That is as far as I can take it in terms of defense.

Speaker #10: Okay . Thank you .

Mark Freshney: Okay. Thank you.

Speaker #1: We have a follow up question from the line of Dominik Nesh from Barclays . Please go ahead .

Operator: We have a follow-up question from the line of Dominic Nash from Barclays. Please go ahead.

Speaker #9: Thank you . Yeah . Thank you for this follow up question . It's actually on Hornsea Three and the numbers announced sort of yesterday .

Dominic Nash: Thank you. Thank you for this follow-up question. It's actually on Hornsea Three and the numbers announced sort of yesterday. I just need some clarification on them, if you can help me out, please. Could you work out whether my math is right? You basically said that you've spent DKK 20 billion to date. Apollo are paying you DKK 10 billion for what you've spent to date, so fine. You also say you're doing DKK 70 to 75 billion of CapEx still to go for the project, so DKK 90 to 95 billion in total. And you say about a third of that's transmission, I think. If you then take Apollo's DKK 39 billion contribution, and DKK 10 billion has been used for buying into the project for historics, that leaves DKK 29 billion remaining.

Speaker #9: I just need some clarification on them . If you can help me out , please . So could you could you work out whether my maths are right ?

Speaker #9: You basically say that you've spent 20 billion kroner to date . Apollo are paying you 10 billion for what you've spent to date .

Speaker #9: So fine . You also say you're doing 70 to 75 billion of CapEx still to go for the project . So 90 to 95 in total .

Speaker #9: And you say about a third of that is transmission . I think . But you then if you then take Apollo's 39 billion contribution and ten has been used for for buying into the project for Historics , at least 20 .

Speaker #9: Nine remaining . How does that 29 fit into the 70 to 75 ? Still to go at 50% ownership ? And on that , I think that the transmission might be the one that's a bit bit odd .

Dominic Nash: How does that DKK 29 fit into the DKK 70 to 75 still to go at 50% ownership? On that, I think the transmission might be the one that's a bit odd. Is that in or out of the amount of cash that they're paying into? Is there the sort of debt associated with it? Have you got some other way of getting that one financed? Thank you.

Speaker #9: Is that in or out of the amount of cash that they're paying into? And is there the sort of debt associated with it, or have you got some other way of getting that one financed?

Speaker #9: Thank you .

Speaker #5: Dominic . Just a starting point for it's a bit difficult to follow sort of your math over the phone . But I think one material element in your math is that 7075 is the total project and not what is remaining .

Trond Westlie: Dominic Nash, just a starting point for it's a bit difficult to follow sort of your math over the phone. I think one material element in your math is that DKK 70, DKK 75 is the total project and not what is remaining. I do think that if you take the rest of your math together with the IR, I think they will be better off guiding you through it.

Speaker #5: But I do think that if you take the rest of your math together with the IR , I think they will be better of guiding you through it .

Speaker #9: Thank you very .

Speaker #20: Much .

Dominic Nash: Thank you very much.

Speaker #1: We have a follow up question from the line of Deepa Venkateswaran from Bernstein . Please go ahead .

Operator: We have a follow-up question from the line of Deepa Venkateswaran from Bernstein. Please go ahead.

Speaker #13: Thank you for taking my follow up question . So the question I have is on the legal process in the US for Revolution Wind .

Deepa Venkateswaran: Thank you for taking my follow-up question. The question I have is on the legal process in the US for Revolution Wind. The stop work orders allowed you to start construction. Seems to be going well. What happens if you finish constructing the project, but you've not resolved the underlying challenge of the stop work order? Can you start already selling the power and so on and energize? Or will it kind of come to a standstill? You know, in some scenario, I don't know, if you lose the appeal at a later stage after one or two years, will you then be forced to decommission? I'm just thinking about what happens given that now you are constructing and so far the legal process might take much longer to settle.

Speaker #13: So the stop work orders allowed you to start construction seems to be going well . What happens if you finish constructing the project but you've not resolved the underlying challenge of the stop work order ?

Speaker #13: Can you can you start already selling the power and so on and energize or will it kind of come to a standstill ? And , you know , in some scenario , I don't know if you lose the appeal at a later stage after 1 or 2 years , will you then be forced to decommission ?

Speaker #13: I'm just thinking about what happens , given that now you are constructing and so far the legal process might take much longer to settle , it might take longer than your construction timeline .

Deepa Venkateswaran: It might take longer than your construction timeline. If you could just elaborate on those scenarios. Thank you.

Speaker #13: So if you could just elaborate on those scenarios . Thank you .

Speaker #2: Thank you . I will be brief . The impact of the injunction relief allows us to continue the project , to continue constructing , and also to produce power .

Rasmus Errboe: Thank you, Deepa. I will be brief. The impact of the injunction relief allows us to continue the project, to continue constructing and also to produce power.

Speaker #1: We have a follow up question from the line of Lars Heindorf from Nordia . Please go ahead .

Operator: We have a follow-up question from the line of Lars Heindorff from Nordea. Please go ahead.

Speaker #12: Yeah . Hello . Thank you for taking my follow up . And very fortunate to be asked question because it's also regarding Revolution Wind .

Lars Hindorf: Yeah. Hello. Thank you for taking my follow-up, and very fortunate to be after Deepa's question, because it's also regarding Revolution Wind. Now, you got to start work on the 22 August. You got the injunction filing on the 17 September. That is now sorry, 49 days ago. If I'm correct, you have installed roughly seven turbines in that period. You have 13 turbines left to install for Revolution Wind. How long do you expect that will take?

Speaker #12: Now you got to start work on the 22nd of August . You got the injunction filing on on the 17th of December . That is now 47 or so , 49 days ago .

Speaker #12: And if I'm correct , you have installed roughly seven turbines in that period . You have 13 turbines left to install for Revolution Wind .

Speaker #12: How long do you expect that will take ?

Speaker #2: Thank you , thank you . Lars . So , so the guidance we give on on a progress is that we we basically guide on the Cod .

Rasmus Errboe: Thank you. Thank you, Lars. The guidance we give on progress is that we basically guide on COD. Of course, it is also, as it always is, it is also relevant when you install all the turbines and also when you can have first power, and that we expect during H1.

Speaker #2: But but of course it is also as it always is . It is also relevant when you install all the turbines and also when you , when you can have first power .

Speaker #2: And that we expect during H1 .

Speaker #12: But is it fair to assume normally I think installation versus they can do one and a half , two days and then maybe winter period it will be longer four days , something like that .

Lars Hindorf: Is it fair to assume normally, I think, installation versus they can do one and a half, two days, and then maybe winter period, it will be longer, four days, something like this. Is that a fair assumption?

Speaker #12: Is that a fair assumption ?

Speaker #2: I look forward to telling you about the construction progress on when we are done with the year , and there will be very specific about how far we have come on on the turbine installation as well .

Rasmus Errboe: Lars, I look forward to telling you about the construction progress on when we are done with the year. There, I will be very specific about how far we have come on the turbine installation as well. It is moving forward quite well right now. Of course, we are also entering a period with more uncertainty on the weather. Right now, turbine installation on Revolution Wind is going really well.

Speaker #2: It is it is moving . It is moving forward quite well right now . But of course we are also entering a period with more uncertainty on the weather .

Speaker #2: But right now , turbine installation on Revolution Wind is going really , really well .

Speaker #12: All right . Thank you .

Lars Hindorf: All right. Thank you.

Speaker #1: We have a follow up question from the line of Rob Pullen from Morgan Stanley . Please go ahead .

Operator: We have a follow-up question from the line of Robert Pulleyn from Morgan Stanley. Please go ahead.

Speaker #18: Yeah sure . Thank you . May I ask the onshore US business ? I know this is a bit different to the vein we've had so far during the rights issue process .

Roald Hartvigsen: Yeah, sure. Thank you. May I ask on the onshore US business, I know this is a bit different to the vein we've had so far. During the rights issue process, you talked about effectively separating this out legally and financially into its own standalone entity. Is that still the case? Any further strategic plan for this, given, of course, there is a somewhat shortage of power in the US and quite a lot of optimism around that market. Thank you very much.

Rob Pulleyn: Yeah, sure. Thank you. May I ask on the onshore US business, I know this is a bit different to the vein we've had so far. During the rights issue process, you talked about effectively separating this out legally and financially into its own standalone entity. Is that still the case? Any further strategic plan for this, given, of course, there is a somewhat shortage of power in the US and quite a lot of optimism around that market. Thank you very much.

Speaker #18: You talked about effectively separating this out legally and financially into its own standalone entity . Is that still the case ? And any further strategic plans for this , given ?

Speaker #18: Of course , there is a somewhat shortage of power in the US and quite a lot of optimism around that market . Thank you very much .

Speaker #2: Thank you . Thank you , Rob . You are right that we have progressed our separation of our US onshore business and as of 1st of October , our our onshore business has become a separate business unit .

Rasmus Errboe: Thank you. Thank you, Rob. You are right that we have progressed our separation of our US onshore business. As of 1 October, our onshore business has become a separate business unit reporting into our global development chief. The Americas onshore business will continue to focus on development and operations of the projects within the US. We have a pipeline of 6, 7 GW of projects with capacity that meets the definition of sort of IRS qualification through 2029. There are ample of opportunities in the market. Also, the two projects that we have under construction, so Old 300 Solar Center in Texas and also Badger Wind in North Dakota, are moving forward really well.

Speaker #2: Reporting into our global development chief and the Americas onshore business will then continue to focus on development and operations of the projects within the US .

Speaker #2: We have a pipeline of 6.7GW of projects with capacity that meets the definition of sort of IRS qualification through 2029 . And there are envelope opportunities in in the market .

Speaker #2: And also the two projects that we have under construction . So all 300 beds in in Texas and also batch of wind in North Dakota are moving forward really well .

Speaker #1: Ladies and gentlemen , that was the last question . I would now like to turn the conference back over to CEO Rasmus Errboe for any closing remarks .

Operator: Ladies and gentlemen, that was the last question. I would now like to turn the conference back over to CEO Rasmus Errboe for any closing remarks.

Speaker #2: Thank you all very much for joining . We appreciate the interaction and the interest . As always . And if you have any further questions , please do not hesitate to reach out to our IR team who will be here to answer all of them .

Rasmus Errboe: Thank you all very much for joining. We appreciate the interaction and the interest as always. If you have any further questions, please do not hesitate to reach out to our IR team, who will be here to answer all of them. Thank you very much. Stay safe and have a great day.

Q3 2025 Orsted AS Earnings Call

Request a DemoDemo

DNN

Orsted

Earnings